中英文工程合同

Contract of Construction Project

合同编号：Contract Number:

工程名称：Project Name:

发包方（甲方）：工程设计顾问（北京）

Employer (Party A): International Consulting Engineers ( Beijing) Limited

承包方（乙方）：中寰艺高建筑装饰工程有限公司

Contractor (Party B): Zhong Huanyigao Building Decoration Engineering Co. , Ltd

根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。

In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract.

第一条工程项目Article 1, Project item

1．工程地点：Project site:

2. 工程范围：Scope of project

3. 工程造价：人民币元整(该造价为包工包料价)

Project cost: PMB Yuan only(Cost of this contract is the contract price for labor and materials)

第二条施工准备Article 2, Preparation for construction

1．甲方协助乙方办理临时水电及垂直运输,提供建筑图纸及有关隐蔽障碍物的资料。

Party A shall assists party B to deal with the procedures of temporary hydropower and vertical transportation and provide architectural drawings and documents of relevant concealed obstacles .

2．乙方：. Party B:

①负责施工区域的临时设施、水电管线的铺设、管理、使用和维修工作；

Be responsible for the works of laying, management, use and maintenance of the temporary facilities, water and electricity pipeline in the construction area.

②组织施工管理人员和材料、施工机械进场；

Organize construction management staff and construction materials, construction machinery enter the Site.

③负责在装修期间保持公共地方清洁及每天负责将装物料弃置于由管理处指定的垃圾收集

处。

Be responsible for keeping public places clean during construction and packing construction material and leaving in the garbage collection place designated by management office each day.

第三条工程期限Article 3 Period of Construction

1. 根据工期和使用需要，商定工程总施工期为天（日历天），自年月日开工

至年月日完工

According to the period of construction and the use need, the total construction period agreed shall be days (Calendar days), start from the date of and complete on the date of .

2．如遇下列情况，经甲方现场代表签证后，工期相应顺延：

Construction period shall be prolonged upon Party A site representative's confirmation when the matters occur as follows.

①按施工准备规定，甲方未协助乙方办理临时水电及垂直运输,影响进场施工；According to the requirements of construction preparation, Party A fail tot assist Party B to apply for temporary water and electricity and vertical transportation and have an impact on Party B construction;

②因甲方提出增减项目而造成重大设计变更，因而影响进度；

The material modification or change of design due to the party A’ s requirement of addition or deletion of project have the effect of hindrance on the progress of works.

③未按合同规定拨付预付款、工程款而影响施工；

Party A fail to pay the advance payment and construction cost to party B and impact the construction progress;

④人力不可抗拒的因素而延误工期。

The delay of schedule of construction due to Force Majeure.

第四条工程质量Article 4 The quality of project

一．本工程质量经双方研究要求达到双方约定之验收标准。

The quality of project should achieve the requirements of acceptance agreed by both parties.

二．乙方必须严格按照施工图纸、说明文件和国家颁发的建筑工程规范、规程和标准进行施工，并接受甲方的监督。

Party B should carry on the construction in strict accordance with drawing, specification file and regulations and specifications authorized by the competent authorities and be under the supervision of Party A.

三．乙方在施工过程中必须遵守下列规定：Party B should, during the construction, comply with the provisions as follows:

1．由乙方提供给甲方的所有材料必须经甲方同意方可使用，未按要求购买严禁使用；

All materials provided by Party B should be subject to the approval of Party A prior to use, And none of the same being bought without conformity with Party A requirements can be used.

2．隐蔽工程必须经甲乙双方检查，方可进行下一道工序；

The concealed works should be checked by both parties before the next progress;

3．工程竣工后，乙方按规定对工程实行保修，保修时间自通过竣工验收之日算起，保修期一年。

Party B shall take the liability of maintenance following the complete of works. The period of maintenance shall be one year from the day of acceptance of complete.

第五条工程价款的支付与结算Article 5 Payment and settlement of the contract price

合同总价× 50 %, 即元The total contract price × 50%, which is Yuan.

中期款The payment of medium-term

工程进度过半三日内Within 3 (three) days after the progress more than half.

合同总价× 40 %, 即元The total contract price × 40%, which is Yuan.

尾款Final Payment

竣工验收结算后七日内Within 7 (seven) days after the completion acceptance and settlement.

合同总价× 10 %, 即元The total contract price × 10%, which is Yuan.

第六条施工与设计变更Article6 The Modification of Construction and Design

一．乙方交付的设计图纸、说明和有关技术资料，作为施工的有效依据，开工前由甲方组织签字认同，作为施工的补充依据，甲、乙双方均不得擅自修改。

Design drawing, illustration and relevant technical data consigned by party B are the basis for construction and shall be confirmed by party A’s signature, which is deemed as the supplementary basis and shall be modified by any party without authorization.

二．施工中如发现因甲方要求而发生的设计错误或严重不合理的地方，乙方应及时以书面形式通知甲方，由甲方及时会同乙方等有关单位研究确定修改意见或变更设计文件，乙方按修改或变更的设计文件进行施工。若发生增加费用（包括返工损失、停工、窝工、人员和机构设备调迁、材料构配件积压的实际损失）由甲方负责，并调整合同造价。

If and when any error or material unreasonable problem of design due to party A’s requirement, Party B shall notify Party A promptly in writing and decide the amendment or modification of the design documentation by the consultation and negotiation between parties and units concerned. Party B shall carry out construction according to the design documents modified or changed. If project cost increase (including the actual loss of rework loss, stoppage or slowdown, personnel and machine equipment relocated, material structures, fixtures backlog), shall be responsibility by Party A, and be adjusted the contract price together with Party B.

三．乙方在保证工程质量和不降低设计标准的前提下，提出修改设计、修改工艺的合理化建议，经甲方、设计单位或有关技术部门同意后采取实施。

Any reasonable suggestion on the modifications of design and craft proposed by Party B, subject to the quality and without reducing standards of design, could be carried out upon the approval of Party A, design unit or concerned technical department.

四．甲方如需设计变更，必须作出正式修改通知书和修改图纸，乙方才予实施。重大修改和增加造价时，必须另行协商，乙方才予实施。

Party A should, if any necessary design change, make the formal amendment and modify drawings for Party B’s implementation.. Material changes and cost increased must be negotiated by both parties before Party B implement the same.

第七条工程验收Article 7 Acceptance of project

一．工程施工中地下工程、结构工程必须具有隐蔽验收签证、试水、抗渗等验收合格记录。甲方须及时办理验收签订手续。

The underground engineering, structural engineering in the construction of project should be checked and with issue of certificate and the record of acceptance of water test,

anti-permeability and so on. Party A should deal with the acceptance signed formalities timely.

二．工程竣工验收后，甲方才可使用Party A can use the project after completion acceptance

在规定的保修期内，凡因施工造成的质量缺陷应由乙方无偿保修。其保修条件、范围和期限按城乡建设环境保护部（84）城建字第79号通知印发的《建筑工程保修办法（试行）》执行。

In the provision warranty period, any construction quality defects, Party B should make maintenance free of the quality defect due to construction, the scope and duration carry out according to the issuance of Cheng Jian No. 79 notification " Construction engineering guarantee measures (Trial) "by Urban and Rural Construction and Environmental Protection Department (84).

第八条违约责任Article 8 Liability for breach of contract

乙方的责任：Responsibility of Party B:

一．工程质量不符合合同规定的，负责无偿修理和返工。

Take charge of gratis repair and rework if project quality doesn't meet contact's stipulation

二．工程不能按合同规定的工期交付使用的，按合同中关于建设工期提交或拖后的奖罚规定偿付逾期罚款。

If fail to deliver the construction according to the contract on time, The overdue fines according to punishment or award of the provision concerning the delivery or delay.

甲方的责任：The responsibility of Party A:

一．未能按照合同的规定履行自己应负的责任，除竣工日期得以顺延外，还应赔偿乙方由此造成的实际损失。

Failed to fulfill their responsibilities in accordance with the provisions of the contract, in addition to the completion date to be postponed should be compensation for the actual loss of Party B .

二．工程中途停建、缓建或由于设计变更以及设计错误造成的返工，应采取措施弥补或减少损失。同时，赔偿乙方由此造成的停工、窝工、返工、倒运、人员和机械设备调迁、材料和构件积压的实际损失。

The ongoing project is stopped, postponed or due to design changes and rework caused by design errors, should take measures to remedy or reduce losses. At the same time, compensate Party B the actual loss of work stoppage, slowdown, re-dispatch rework, reshipment, staff and mechanical equipment relocating, the backlog of materials and components.

第九条纠纷解决办法Article 9 Dispute settlement

任何一方违反合同规定，双方协商不成，均可向北京仲裁委员会申请仲裁。

Either party could, if any party’s breach and fail to negotiation, submit the application of arbitration to the Beijing Arbitration Committee

第十条附则Article 10 Supplementary

一．本合同一式贰份，甲乙双方各执正本一份。

This contract is execute in two counterparts, each party holds a single original.

二．本合同自双方代表签字，加盖双方公章或合同专用章即生效。工程竣工验收符合要求，待保修期满后合同终止。

The contract becomes effective after signing and sealing by both parties on this foregoing date. The project final acceptance meet the requirements, after the expiry of warranty, ends the contract.

甲方（盖章）：Party A (seal): 乙方（盖章）：Party B (seal):

委托代理人（签章）：Agent 委托代理人（签章）：Agent

电话：Tel: 电话：Tel:

日期：Date: 日期：Date:

最新国际承包工程合同(中英完整版)

Contract for Works of Civil Engineering Construction 土木工程施工合同 This CONTRACT is made on the _th of_(month), _(year) by and between_(hereinafter called “ Party A ”) of the one part, and _(hereinafter called “ Party B ”) of the ot _公司(以下简称“雇主”)与_公司(以下简称“承包商”)于_年_月_日特签订本合同。 WHEREAS 鉴于。。。 NOW THEREFORE THIS CONTRACT WITNESSETH that it is hereby agreed by and between the parties hereto as follows: 双方达成协议如下： civil engineering 土木工程 Chapter 1 Definitions and Interpretation Article 1 Definitions In the Contract (as hereinafter defined) the following words and expressions shall have the meanings hereby assigned to them, except where the context other requires: 第一条定义 本合同(按下文所定义的)中的下列词和用语，除文中另有要求者外，应具有本条所赋予的含 义： 1.1 “ employer m”eans the person named as such in this contract and the legal successorsin title to such person, but not (except with the consent of the Contractor) any assignee of such pers.on 1.1“雇主”是指本合同所指明的当事人以及取得当事人资格的合法继承人，但除非承包商同意，不包 括此当事人的任何受让人，本合同中的雇主为_(填入名称)。 1.2 “ Contractor ” means the person whose te h n a d s er been accepted by the Employer and the legal successors in title to such pers b o u n t not (except with the consent of the Employer) any assignee of such pers.on 1.2承包商是指其标书已为雇主接受的当事人以及取得此当事人资格的合法继承人，但除非雇主同意，不指此当事人的任何受让人。本合同中的雇主为_(填入名 1.3 “ Subcontractor e”anms any person named in the Contract as a Subcontractor for a part of the Works or any person to whom a part of the works has been subcontracted with the consent of the engineer and the legal successors in title to such person, but not any assignee of any such person. 1.3 “分包商”是指本合同中指定作为分包工程某一部分的分包商的任何当事人，或由工程师同意已将工程的某一部分分包给他的任何当事人以及取得该当事人资格的合法继承人，但不指此当事人的任何受让人。 1.4 “ Engineer ” means the person appointed by the employer to act as Engineer for the purpose of the Contract and named as such in this Contract. 1.4工程师”是指雇主为本合同目的而指定作为工程师。本合同中的工程师是指_(填入名称)。 1.5 “ Engin eer Represe ntative ” means a pers on appo in ted from time to time by the engin eer un der clause 9.2. 1.5工程师代表”是指工程师根据9.2条款随时指定的人员。 1.6 “ Con tract ” mea ns this Con tract, the Specificatio n, the Drawi ngs, the Bill of Quan tities, the

国际工程协议(中英文对照)

Memorandum of Understanding This Memorandum of Understanding(MOU)is made and entered into this 8th day of sep,2012 between: The Consortium whose principal place of business is in PRC and consisting,inter alia of i)China International Fund Limited; ii)China Railway Construction Corporation; (the Consortium)of the one part, and the Government of the Republic of Sierra Leone(GOSL) The Consortium and GOSL are sometimes referred to in this MOU individually as a “Party”and,collectively, as the “Parties” WHEREAS A. In furtherance of the mutual desires of the Parties to develop a strategic partnership and cooperation to ensure that the rich potential resources of Sierra Leone benefit the people of Sierra Leone through improved welfare of the People of Sierra Leone through the provision of services and infrastructure and the strengthening of Sierra Leone’s national development through experience sharing(South-South Cooperation) particularly in the sphere of construction of core infrastructure assets; B.To bring to the People of Sierra Leone, in the spirit of mutual respect and with a view of transferring relevant technical, organizational and management skills necessary to bring to the C.Republic of Sierra Leone to a higher level of development and prosperity; D.GOSL desires assistance in sourcing,implementing or prequalifying skilled and competent contractors and financiers for the purpose of its national development priorities award of contracts for projects specifically in the following priority areas; 1.MINISTRY OF WORKS,HOUSING AND INFRASTRUCTURE - Remedial Roads Rehabilitation - Development of new city - Construction and Operation of Ⅰ) Affordable Social Housing Infrastructure Ⅱ) National trunk and feeder roads Ⅲ) National railways Ⅳ) Bridges and drainage systems at national ,regional and local levels Ⅴ) Airports 2.MINISTRY OF ENERGY AND WATER RESOURCES: - Construction and operation of: Ⅰ) Thermal electric generation systems Ⅱ) Hydro power systems & infrastructure Ⅲ) Water supply systems & infrastructure Ⅳ) Other renewable power generation systems 3.PETROLEUM DIRECTORATE

中英文建筑工程合同(ContractofConstructionProject)

编号：_______________ 本资料为word版本，可以直接编辑和打印，感谢您的下载 中英文建筑工程合同 (ContractofConstructionProject) 甲方：___________________ 乙方：___________________ 日期：___________________

Contract of Construction Project 合同编号：Contract Number: 工程名称：Project Name: 发包方(甲方)： ______________________________ Employer (Party A): ________________________ 承包方(乙方)： ______________________________ Contractor (Party B): ________________________ 根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。 In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract. 第一条工程项目Article 1, Project item 1 .工程地点：Project site: 2. 工程范围：Scope of project 3. 工程造价：人民币元整(该造价为包工包料价) Project cost: PMB Yuan only(Cost of this contract is the contract price for labor and materials) 第二条施工准备Article 2, Preparation for construction 1 .甲方协助乙方办理临时水电及垂直运输，提供建筑图纸及有关隐蔽障碍物的资料。 Party A shall assists party B to deal with the procedures of temporary hydropower and vertical transportation and provide architectural drawings and documents of relevant concealed obstacles . 2 .乙方：.Party B: ①负责施工区域的临时设施、水电管线的铺设、管理、使用和维修工作； Be responsible for the works of laying, management, use and maintenance of the temporary facilities, water and electricity pipeline in the construction area. ②组织施工管理人员和材料、施工机械进场；

施工合同中英文模板-construction-contract

编号：_______________本资料为word版本，可以直接编辑和打印，感谢您的下载 施工合同中英文模板-construction-contract 甲方：___________________ 乙方：___________________ 日期：___________________

工程合同 PO No.: XXXXXXX Date of signature: 签约日期： Seller: 乙方： This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below: 甲乙双方经友好协商，一致就供应下列产品，达成如下条款： 1. Scope of Supply and Price 工作范围及价格明细 2. Technical Requirement, Quality Requirement, Standard & Warranty Period: Seller shall carried out the construction in strict accordance with the National Standard and the requirements stipulated in the Technical Agreement No. which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service. 技术要求、质量要求、技术标准和质保期限 ：按国家标准和双方签定的技术协议(编号： 见附件)施工, 质保期为投产后1年。 3. Job Sites: 施工地点： 4. Construction Equipment, Tools & Field Personnel Management: 施工设备工具及现场人员管理： Buyer: 甲方：

工程设计合同(中英文)

建设工程设计合同 Engin eeri ng Service Con tract (专业建设工程设计合同) (Professio nal Engin eeri ng Service Con tract For Con structio n Project) 工程名称：___________ Name of the project: 工程地点：____________________________ Locati on of the project: 合同编号：__________________________________________ (由设计人编填) Con tract No.: (Filled in by the Desig ner) 设计证书等级：_____________________________ Level of the desig n certificate: 发包人：_________________________ Employer: 设计人：______________________________ Desig ner: ____________________ 签定日期：____________________________________________ Date of con tract: 江苏省建设厅监制 江苏省工商行政管理局 Supervised by: Jia ngsu Provin cial Departme nt of Con structi on Jiangsu Provincial Administration for Industry and Commerce

xxx工程合同中英文版(标准版)

xxx engineering contract xxx工程合同 Contract No.: 合同编号： Party A: xxxCompany Limited 甲方：xxx有限公司 Party B:xxx Company Limited 乙方：xxx有限公司

This contract is made and entered into on the day of , 2014 by the following Parties in . 本合同于2014年月日由以下当事方在签署。 Party A: xxx Company Limited, 甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxx Party B:xxx Company Limited, 乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxx Party A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party. 甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。 1. Work Content and Requirements 1. 工作内容、要求 1.1 In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Project standard and quality standard stipulated by Ministry of Engineering of the Union of xx. 1.1 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。 2. Contract Period 2. 合同期限 2.1 Work period for the Road Construction Project: the work shall be completed within 2 month upon signing the Contract. The condition of handover is that the Project Inspection & Acceptance Team constituted by Party A, shall issue the Inspection & Acceptance Sheet after onsite inspection. 2.1 本次工程时间周期：合同签订后14个工作日内完成，并以甲方组成的竣工验收小组现场检验并出具 验收单为竣工交接条件。 2.2 This contract shall be implementedafter this is duly signed by the legal representatives or authorized representatives of the Parties and stamped with the seals of the Parties, and closed after the onsite acceptance of the Project and Contract payment. 2.2 本合同自双方法定代表人或授权代表人签字盖章后生效，现场验收合格、款项支付完毕后关闭。 3. Health, Safety and Environment Principles (HSE) 3. 健康、安全和环境原则(HSE) 3.1 The staff from Party B shall follow the arrangement of Local government and Party A (or its representatives), and comply with the laws and regulations of Myanmar as well as rules and regulations on Health, Safety and Environment (HSE) of Party A. 3.1 乙方工作人员必须听从地方政府、甲方人员（或代表）的安排，遵守缅甸法律、法规和甲方的安全 环境健康规章制度等。 3.2 Before or during the implementation of this Project, Party B shall acknowledge, avoid and prevent the possible damage of the Project to the surrounding environment and other affiliatedfacilities, and the resulting losses shall be borne by Party B.

中英文工程合同

Contract of Construction Project 合同编号：Contract Number: 工程名称：Project Name: 发包方（甲方）： Employer (Party A): 承包方（乙方）： Contractor (Party B): 根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。 In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract. 第一条工程项目Article 1, Project item 1．工程地点：Project site: 2. 工程范围：Scope of project 3. 工程造价：人民币元整(该造价为包工包料价) Project cost: PMB Yuan only(Cost of this contract is the contract price for labor and materials) 第二条施工准备Article 2, Preparation for construction 1．甲方协助乙方办理临时水电及垂直运输,提供建筑图纸及有关隐蔽障碍物的资料。 Party A shall assists party B to deal with the procedures of temporary hydropower and vertical transportation and provide architectural drawings and documents of relevant concealed obstacles . 2．乙方：. Party B: ①负责施工区域的临时设施、水电管线的铺设、管理、使用和维修工作； Be responsible for the works of laying, management, use and maintenance of the temporary facilities, water and electricity pipeline in the construction area. ②组织施工管理人员和材料、施工机械进场； Organize construction management staff and construction materials, construction machinery enter the Site. ③负责在装修期间保持公共地方清洁及每天负责将装物料弃置于由管理处指定的垃圾收集处。 Be responsible for keeping public places clean during construction and packing

施工合同中英文模板

合同协议模板 Construction Contract 工程合同 PO No.: XXXXXXX Buyer:. Date of signature: 甲方:签约日期： Seller: 乙方: This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below: 甲乙双方经友好协商，一致就供应下列产品，达成如下条款： 1. Scope of Supply and Price 工作范围及价格明细 2. Technical Requirement, Quality Requirement, Standard & Warranty Period: Seller shall carried out the construction in strict accordance with the National Standard and the requirements stipulated in the Technical Agreement No. ________which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service. 技术要求、质量要求、技术标准和质保期限: 按国家标准和双方签定的技术协议（编号：______见附件）施工，质保期为投产后1年。 3. Job Sites: 施工地点： 4. Construction Equipment, Tools & Field Personnel Management: 施工设备工具及现场人员管理： 可编辑可修改，欢迎下载

工程施工合同中英文版

工程施工合同中英文版 Construction Contract PO No.: XXXXXXX Buyer:. Date of signature: 甲方: 签约日期： Seller: 乙方: This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below: 甲乙双方经友好协商，一致就供应下列产品，达成如下条款： 1. Scope of Supply and Price 工作范围及价格明细 2. Technical Requirement, Quality Requirement, Standard & Warranty Period: Seller shall carried out the construction in strict accordance with the National Standard and the requirements stipulated in the Technical Agreement No. ________which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service. 技术要求、质量要求、技术标准和质保期限: 按国家标准和双方签定的技术协议（编号：______见附件）施工，质保期为投产后1年。 3. Job Sites: 施工地点： 4. Construction Equipment, Tools & Field Personnel Management: 施工设备工具及现场人员管理： (1) All the construction equipment and tools shall be provided by Seller. 所有施工用设备及工具由乙方自带。 (2) Buyer will coordinate and arrange the electricity and water supply on the site. 现场施工用水电由甲方协调安排。 (3) Buyer will be responsible for all the lifting work during the construction on site. 现场施工过程中的吊装工作由甲方负责。

建设工程施工合同中英文翻译件

工程编号： ___________________ Project No.: ___________________ 合同编号： ___________________ Contract No.: __________________ 建设工程施工合同 Con structi on Con tract for Con structi on Projects (GF-2013-0201 ) 工程名称： Name of project: 工程地点： Locati on of project: 发包人： Clie nt: 承包人：

工 商 行 政 管 理 总 局 Made by Min istry of Hous ing Urba n-Rural Developme nt State Admi nistrati on for In dustry & Commerce of the P 目录 Table of Contents 第一部分合同协议书 .......................................... ................ 错误! 未 定 义 书 签。 Part I Con tract Agreeme nt ........................................................... .............................. 错误! 未 定 义 书 签。 ...17 I. Project Overview ................. ?... .......... ?... ........... ?... ......... ?... ......... ?... ......... ???17 、合同工期 ... ....... ... ....... ... ....... .............. .......... ........ ... ........... . (30) II. Project Duratio n un der Con tract ?… ......... … ..... ?….....?… ....... … ......... ?：：... Con tractor: 住房和城乡建设部 制定 .R.C 、工程概况

工程施工合同中英文

工程施工合同中英文 xxx engineering contract xxx工程合同 Contract No.: 合同编号： Party A: xxxCompany Limited 甲方：xxx有限公司 Party B:xxx Company Limited 乙方：xxx有限公司 This contract is made and entered into on the day of , XXXX by the following Parties in . 本合同于XXXX年月日由以下当事方在签署。 Party A: xxx Company Limited, 甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxx Party B: xxx Company Limited, 乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxx Party A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party. 甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。 1. Work Content and Requirements 1. 工作内容、要求 1.1 In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Project standard and quality standard stipulated by Ministry of Engineering of the Union of xx. 1.1 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。 2. Contract Period 2. 合同期限 2.1 Work period for the Road Construction Project: the work shall be completed within 2 month upon signing the Contract. The condition of handover is that the Project Inspection & Acceptance Team constituted by Party A, shall issue the Inspection & Acceptance Sheet after onsite inspection. 2.1 本次工程时间周期：合同签订后14个工作日内完成，并以甲方组成的竣工验收小组现场检验并出具验收单为竣工交接条件。

国际工程施工合同新(官方版)

编号：QJ-HT-0302 国际工程施工合同新(官方 版) Both parties shall perform their obligations as agreed in the contract or in accordance with the law within the term of the contract. 甲方：_____________________ 乙方：_____________________ 日期：_____________________ --- 专业合同范本系列下载即可用---

国际工程施工合同新(官方版) 说明：该合同书适用于甲乙双方为明确各自的权利和义务，经友好协商双方同意签署合同，在合同期限内按照合同约定或者依照法律规定履行义务，可下载收藏或打印使用（使用时请先阅读条款是否适用）。 定义和释义 1．1 在本合同中，除按上下文另具意义者外，下列词语应解释如下： “业主”指第二章中所指定的雇用承包人的一方或其权利合法继承人，但不包括业主的受让人，经承包人同意者除外。 “承包人”指标书已被业主接受的某个或某些人、商行或公司，包括其他人代表，继承人和业经认可的受让人。 “工程师”指第二章中所指定的工程师，或由业主随时任命且书面通知承包人以代替指定工程师履行合同职责的其它工程师。 “工程师代表”指任何常驻工程技术人员、监理工程师，或由业主或工程师随时任命的履行本合同第二条规定职责的任何工程现场监督，其权限上工程师书面通告承包人。 “工程”包括永久性工程和临建工程。

“合同”指合同条款、技术规范、图纸、标价的建筑工程清单、单价和价格表（如果有），还可指标书、接受证书以及承包协议（如已完成）。 “合同价格”指在接受证书中确定的数额，可按本合同以下条款规定增减。 “建筑设备”指工程施工和维修中或有关施工和维修所需的全部设备或物品，不论任何性质，但不包括旨在构成或正在构成永久性工程某一部分的材料或其它物品。 “临建工程”指工程施工或维修或有关工程施工或维修所需的各种临时工程。 “永久性工程”指按合同将施工和维修的永久工程。 “技术规范”指在标书或任何标书更改中提及的规范，或由工程师随时可能增加或书面同意增加的部分。 “图纸”指技术规范中规定的图纸，经工程师书面同意对此种图纸所作的任何更改，以及可由工程师随时提供或书面认同的其他图纸。 “工地”指工程师设计的永久性或临建工程施工所需的土地及其他场地，包括地面、地下、在之上或通过部分，以及由业主所提供的用作临时储存或

工程承包合同中英文

工程承包合同 Contract of Construction Project 合同编号： Contract Number: 工程名称： Project Name: 发包方（甲方）：工程设计顾问（北京）有限公 司 Employer (Party A): International Consulting Engineers ( Beijing) Limited 承包方（乙方）：中寰艺高建筑装饰工程有限公司 Contractor (Party B): Zhong Huanyigao Building Decoration Engineering Co. , Ltd 根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。 In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract. 第一条工程项目Article 1, Project item 1．工程地点： ,Project site: 2．工程范围： Scope of project 3．工程造价：人民币元整 (该造价为包工包料价) 3, Project cost: PMB Yuan only (Cost of this contract is the contract price for labor and materials) 第二条施工准备 Article 2, Preparation for construction 1．甲方协助乙方办理临时水电及垂直运输,提供建筑图纸及有关隐蔽障碍物的资料。 Party A shall assists party B to deal with the procedures of temporary hydropower and vertical transportation and provide architectural drawings and documents of relevant concealed obstacles . 2．乙方：. Party B: ①负责施工区域的临时设施、水电管线的铺设、管理、使用和维修工作； Be responsible for the works of laying, management, use and maintenance of the temporary facilities, water and electricity pipeline in the construction area. ②组织施工管理人员和材料、施工机械进场；

中英文对照-工程施工合同范本-精选.docx

工程施工合同 Contract 合同编号( Contract NO. )： 签订日期( Date )： 发包方（简称甲方） Party A: 承包方（简称乙方）： Party B: 根据《中华人民共和国合同法》以及其他有关法律法规规定的原则，结合本工程的具体情况，甲、乙双方在平等、自愿、协商一致的基础上达成如下协议，共同遵守。 According to “P.R.C Contract Law”,and other relevant laws and regulations to the specific circumstances of this project, parties A and B have hereby equally and voluntarily entered into the following agreement executed on the basis of mutual respect. 1.工程概况 Project overview 1.1工程名称： Project name: 1.2工程地点： Project location: 1.3工程范围： A. 新研发中心和新厂房的网络综合布线系统的施工； B. 数据中心的建设，主要包含：数据中心的装饰工程、电气系统、空调系统、机房闭路监控系统、机房门禁系统、消防系统改造、机柜系统等。 Project contents: A. The new R & D and new plant construction of network cabling systems; B. Data Center, mainly includes: data center decoration and electrical systems, air-conditioning systems, CCTV systems, access control systems, firefighting system reform, server rack systems. 1.4开工条件：合同生效后，甲方预付款到位和现场具备开工条件。 Start conditions: After the commencement of the contract, Party A has started advance and on-site conditions in place.