搜档网
当前位置:搜档网 › FIDIC红皮书1999(中英文对照)

FIDIC红皮书1999(中英文对照)

FIDIC红皮书1999(中英文对照)
FIDIC红皮书1999(中英文对照)

FIDIC红皮书1999(中英文对照)

Fédération Internationale Des Ingénieurs-Conseils

通用条件

General Conditions

1.一般规定

General Provisions

1.1 定义

Definitions

在包括专用条件和本通用条件的合同条件(“本合同条件”)中,以下措辞和用语的含义如下所述。除非上下文中另有要求,指当事人和当事各方的词包括公司和其它法律实体。

In the Conditions of Contract ("these Conditions"), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meanings stated. Words indicating persons or parties include corporations and other legal entities, except where the context requires otherwise.

1.1.1 合同

1.1.1 The Contract

1.1.1.1“合同(Contract)”指合同协议书、中标函、投标函、本合同条件、规范、图纸、资料表、以及在合同协议书或中标函中列明的其它进一步的文件(如有时)。

1.1.1.1 "Contract" means the Contract Agreement, the Letter of Acceptance, the Letter of Tender, these Conditions, the Specification, the Drawings, the Schedules, and the further documents (if any) which are listed in the Contract Agreement or in the Letter of Acceptance.

1.1.1.2“合同协议书(Contract Agreement)”指第1.6款【合同协议】中所说明的合同协议(如有时)。

1.1.1.2 "Contract Agreement" means the contract agreement (if any) referred to in Sub-Clause 1.6 [Contract Agreement].

1.1.1.3“中标函(Letter of Acceptance)”指雇主对投标文件签署的正式接受函,包括其后所附的备忘录(由合同各方达成并签定的协议构成)。在没有此中标函的情况下,“中标函”一词就指合同协议书,颁发或接收中标函的日期就指双方签订合同协议书的日期。

1.1.1.3 "Letter of Acceptance" means the letter of formal acceptance, signed by the Employer, of the Letter of Tender, including any annexed memoranda comprising agreements between and signed by both Parties. If there is no such letter of acceptance, the expression "Letter of Acceptance" means the Contract Agreement and the date of issuing or receiving the Letter of Acceptance means the date of signing the Contract Agreement.

1.1.1.4“投标函(Letter of Tender)”指名称为投标函的文件,由承包商填写,包括已签字的对雇主的工程报价。

1.1.1.4 "Letter of Tender" means the document entitled letter of tender, which was completed by the Contractor and includes the signed offer to the Employer for the Works.

1.1.1.5“规范(Specification)”指合同中名称为规范的文件,及根据合同规定对规范的增加和修改。此文件具体描述了工程。

1.1.1.5 "Specification" means the document entitled specification, as included in

the Contract, and any additions and modifications to the specification in accordance with the Contract. Such document specifies the Works.

1.1.1.6“图纸(Drawings)”指合同中规定的工程图纸,及由雇主(或代表)根据合同颁发的对图纸的增加和修改。

1.1.1.6 "Drawings" means the drawings of the Works, as included in the Contract, and any additional and modified drawings issued by (or on behalf of, the Employer in accordance with the Contract.

1.1.1.7“资料表(Schedules)”指合同中名称为资料表的文件,由承包商填写并随投标函提交。此文件可能包括工程量表、数据、列表、及费率和/或单价表。

1.1.1.7 "Schedules" means the document(s) entitled schedules, completed by the Contractor and submitted with the Letter of Tender, as included in the Contract. Such document may include the Bill of Quantities, data, lists, and schedules of rates and/or prices

1.1.1.8“投标文件(Tender)”指投标函和合同中规定的承包商应随投标函提交的其它所有文件。

1.1.1.8 "Tender" means the Letter of Tender and all other documents which the Contractor submitted with the Letter of Tender, as included in the Contract. 1.1.1.9“投标函附录(Appendix to Tender)”指名称为投标函附录并已填写完毕的文件,附于投标函之后并构成投标函的一部分。

1.1.1.9 "Appendix to Tender" means the completed pages entitled appendix to tender which are appended to and form part of the Letter of Tender.

1.1.1.10 “工程量表(Bill of Quantities)”和“计日工计划(Daywork Schedule)”指资料表中如此命名的文件(如有时)。

1.1.1.10 "Bill of Quantities" and "Day work Schedule" mean the documents so named (if any) which are comprised in the Schedules.

1.1.2 当事各方和当事人

1.1.2Parties and Persons

1.1.

2.1“一方(Party)”指雇主或承包商(根据上下文而定)。

1.1.

2.1 "Party" means the Employer or the Contractor, as the context requires.

1.1.

2.2“雇主(Employer)”指在投标函附录中指定为雇主的当事人或此当事人的合法继承人。

1.1.

2.2 "Employer" means the person named as employer in the Appendix to Tender and the legal successors in title to this person.

1.1.

2.3“承包商(Contractor)”指在雇主收到的投标函中指明为承包商的当事人(一个或多个)及其合法继承人。

1.1.

2.3 "Contractor" means the person(s) named as contractor in the Letter of Tender accepted by the Employer and the legal successors in title to this person(s). 1.1.2.4“工程师(Engineer)”指雇主为合同之目的指定作为工程师工作并在投标函附录中指明的人员,或由雇主按照第

3.4款【工程师的撤换】随时指定并通知承包商的其他人员。

1.1.

2.4 "Engineer" means the person appointed by the Employer to act as the Engineer for the purposes of the Contract and named in the Appendix to Tender, or other person appointed from time to time by the Employer and noted to the Contractor under Sub-Clause

3.4 [Replacement of the Engineer].

1.1.

2.5“承包商的代表(Contractor’s Representitive)”指承包商在合同中指定的或由

承包商按照第4.3款【承包商的代表】随时指定的代表承包商的人员。

1.1.

2.5 "Contractor's Representative" means the person named by the Contractor in the Contract or appointed from time to time by the Contractor under Sub-Clause 4.3 [Contractor's Representative], who acts on behalf of the Contractor.

1.1.

2.6“雇主的人员”指工程师,第

3.2款【工程师的授权】中所指的工程师助理以及所有其他职员、劳工和工程师或雇主的其他雇员;以及所有其他由雇主或工程师作为雇主的人员通知给承包商的人员。

1.1.

2.6 "Employer's Personnel" means the Engineer, the assistants referred to in Sub-Clause

3.2 [Delegation by the Engineer] and all other staff, labour and other employees of the Engineer and of the Employer; and any other personnel notified to the Contractor, by the Employer or the Engineer, as Employer's Personnel.

1.1.

2.7“承包商的人员”指承包商的代表和所有承包商在现场使用的人员,包括职员、劳工和承包商及各分包商的其他雇员;以及其他所有帮助承包商实施工程的人员。

1.1.

2.7 "Contractor's Personnel" means the Contractor's Representative and all personnel whom the Contractor utilises on Site, who may include the staff, labour and other employees of the Contractor and of each Subcontractor; and any other personnel assisting the Contractor in the execution of the Works.

1.1.

2.8“分包商”指合同中指明为分包商的所有人员,或为部分工程指定为分包商的人员;及所有上述人员的合法继承人。

1.1.

2.8 "Subcontractor" means any person named in the Contract as a subcontractor, or any person appointed as a subcontractor, for a part of the Works; and the legal successors in title to each of these persons.

1.1.

2.9“争端裁决委员会”指合同中如此命名的一个或三个当事人,或按照第20.2款【争端裁决委员会的委任】或按照第20.3款【未能同意争端裁决委员会的委任】指定的其他人员(一个或多个)。

1.1.

2.9 "DAB" means the person or three persons so named in the Contract, or other person(s) appointed under Sub-Clause 20.2 [Appointment of the Dispute Adjudication Board] or Sub-Clause 20.3 [Failure to Agree Dispute Adjudication Board]

1.1.

2.10 “FIDIC”指国际咨询工程师联合会。

1.1.

2.10 "FIDIC" means the international federation of consulting Engineers. 1.1.3 日期、检验、期限和完成

1.1.3 Dates, Tests, Periods and Completion

1.1.3.1“基准日期”指提交投标文件截止日前28天的当日。

1.1.3.1 "Base Date" means the date 28 days prior to the latest date for of the Tender 1.1.3.2“开工日期”指按照第8.1款【工程的开工】通知的日期。

1.1.3.2 "Commencement Date" means the date notified under Sub-Clause 8.1 (commencement of works)

1.1.3.3“竣工时间”指在投标函附录中说明的,按照第8.2款【竣工时间】的规定,由开工日期算起到工程或某一区段(视情况而定)完工的日期(包括按照第8.4款【竣工时间的延长】决定的任何延期)。

1.1.3.3 "Time for Completion" means the time for completing the Works or a Section (as the case may be) under Sub-Clause 8.2 [Time for Completion], as stated in the Appendix to Tender (with any extension under Sub Clause 8.4- [Extension of Time for Completion]), calculated from the Commencement Date.

1.1.3.4“竣工检验”指在雇主接收工程或某区段(视情况而定)前按照第9款【竣工检验】进行的检验,此检验可在合同中说明、或由双方协商决定、或以变更的形式被指示进行。1.1.3.4 "Tests on Completion" means the tests which are specified in the Contract or agreed by both Parties or instructed as a Variation, and which are carried. out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Employer.

1.1.3.5“接收证书”指按照第10条【雇主的接收】颁发的证书。

1.1.3.5 "Taking-Over Certificate" means a certificate issued under Clause 10 [Employer's Taking Over].

1.1.3.6“竣工后的检验”指合同中规定的,在雇主接收了工程或某区段(视情况而定)后,按照特殊应用条款的规定进行的检验(如有时)。

1.1.3.6 "Tests after Completion" means the tests (if any) which are specked in the Contract and which are carried out in accordance with the provisions of the Particular Conditions after the Works or a Section (as the case may be) are taken over by the Employer.

1.1.3.7“缺陷通知期”指根据投标函附录中的规定,从工程或区段按照第10.1款【工程或区段的接收】被证明完工的日期算起,到按照第11.1款【完成扫尾工作和修补缺陷】通知工程或该区段(视情况而定)中的缺陷的期限(包括按照第11.3款【缺陷通知期的延长】决定的任何延期)。

1.1.3.7 "Defects Notification Period" means the period for notifying defects in the Works or a Section (as the case may be) under Sub-Clause 11.1 [Completion of Outstanding Work and Remedying Defects], as stated in the Appendix to Tender (with any extension under Sub-Clause 11.3 [Extension of Defects Notification Period]), calculated from the date on which the Works or Section is completed as certified under Sub-Clause 10.1 [Taking Over of the Works and Sections].

1.1.3.8“履约证书”指按照第11.9款【履约证书】颁发的证书。

1.1.3.8 "Performance Certificate" means the certificate issued under Sub Clause 11.9 [Performance Certificate].

1.1.3.9“日”指一个公历日,而“年”指365天。

1.1.3.9 "day" means a calendar day and "year" means 365 days.

1.1.4 款项与支付

1.1.4 Money and Payments

1.1.4.1“接受的合同款额”指雇主在中标函中对实施、完成和修补工程所接受的金额。1.1.4.1 "Accepted Contract Amount" means the amount accepted in the Letter of Acceptance for the execution and completion of the Works and the

1.1.4.2“合同价格”指第14.1款【合同价格】中定义的价格,包括根据合同所做的调整。

1.1.4.2 "Contract Price" means the price defined in Sub-Clause 14.1 [The Contract Price], and includes adjustments in accordance with the Contract.

1.1.4.3“费用”指承包商在现场内或现场外正当发生(或将要发生)的所有开支,包括管理费和类似支出,但不包括利润。

1.1.4.3 "Cost" means all expenditure reasonably incurred (or to be incurred) by the Contractor, whether on or off the Site, including overhead and similar charges, but does not include profit.

1.1.4.4“最终支付证书”指按照第14.13款【最终支付证书的颁发】颁发的支付证书。

1.1.4.4 "Final Payment Certificate" means the payment certificate issued under Sub-Clause 14.13 [Issue of Final Payment Certificate].

1.1.4.5“最终报表”指第14.11款【最终支付证书的申请】中定义的报表。

1.1.4.5 "Final Statement" means the statement defined in Sub-Clause 14.11 [Application for Final Payment Certificate].

1.1.4.6“外币”指可用来支付部分(或全部)合同价格的某种货币,但不指当地货币。

1.1.4.6 "Foreign Currency" means a currency in which part (or all) of the Contract Price is payable, but not the Local Currency.

1.1.4.7“期中支付证书”指根据第14条【合同价格和支付】颁发的付款证书,但不包括最终支付证书。

1.1.4.7 "Interim Payment Certificate" means a payment certificate issued under Clause 14 [Contract Price and Payment], other than the Final Payment Certificate.

1.1.4.8“当地币”指工程所在国的货币。

1.1.4.8 "Local Currency" means the currency of the Country.

1.1.4.9“支付证书”指按照第14条【合同价格和支付】颁发的支付证书。

1.1.4.9 "Payment Certificate" means a payment certificate issued under Clause 14 [ Contract Price and Payment ].

1.1.4.10 “暂定金额”指合同中指明为暂定金额的一笔金额(如有时),用于按照第13.5款【暂定金额】实施工程的任何部分或提供永久设备、材料和服务的一笔金额(如有时)。1.1.4.10 "Provisional Sum" means a sum (if any) which is specified in the Contract as a provisional sum, for the execution of any part of the Works or for the supply of Plant, Materials or services under Sub-Clause 13.5 [Provisional Sums].

1.1.4.11 “保留金”指雇主按照第14.3款【期中支付证书的申请】扣留并按第14.9款【保留金的支付】支付的累计的保留金。

1.1.4.11 "Retention Money" means the accumulated retention moneys which the Employer retains under Sub-Clause 14.3 [Application for Interim Payment Certificates] and pays under Sub-Clause 14.9 [Payment of Retention Money].

1.1.4.12 “报表”指承包商按照第14条【合同价格和支付】申请支付证书时作为申请一部分而提交的报表。

1.1.4.12 "Statement" means a statement submitted by the Contractor as part of an application, under Clause 14 [Contract Price and Payment], for a payment certificate.

1.1.5 工程和货物

1.1.5 Works and Goods

1.1.5.1“承包商的设备”指用于实施和完成工程以及修补缺陷所需要的全部机械、仪器、车辆和其它设备。其中不包括临时工程、雇主的设备(如有时)、永久设备、材料和所有其它将构成或构成永久工程一部分的任何物品。

1.1.5.1 "Contractor's Equipment" means all apparatus, machinery, vehicles and the remedying of any defects. However, Contractor Equipment excludes Temporary Works, Employer’s Equipment (if any), Plant, Materials and any other things intended to form or forming part of the pavement works.

1.1.5.2“货物”指承包商的设备、材料、永久设备和临时工程,或视情况指其中之一。1.1.5.2 "Goods" means Contractor's equipment, Materials, Plant and Temporary Works, or any of them as appropriate.

1.1.5.3“材料”指将构成或构成部分永久工程的各类物品(永久设备除外),包括由承包商按照合同仅负责供应的材料(如有时)。

1.1.5.3 "Materials,, means things of all kinds (other than Plant) intended to form or forming part of the Permanent Works, including the supply-only materials (if any) to be supplied by the Contractor under the Contract.

1.1.5.4“永久工程”指将由承包商按照合同实施的永久工程。

1.1.5.4 "Permanent Works" means the permanent works to be executed by the Contractor under the Contract.

1.1.5.5“永久设备”指将构成或构成部分永久工程的机械、仪器和车辆。

1.1.5.5 "Plant" means the apparatus, machinery and vehicles intended to form or forming part of the Permanent Works.

1.1.5.6“区段”指投标函附录中指明为区段的部分工程(如有时)。

1.1.5.6 "Section" means apart of the Works specified in the Appendix to Tender as

a Section (if any).

1.1.5.7“临时工程”指为了实施和完成永久工程以及修补任何缺陷在现场上所需的各种类型的临时工程(承包商的设备除外)。

1.5.7 "Temporary Works" means all temporary works of every kind (other than Contractor's Equipment) required on Site for the execution and completion of the Permanent Works and the remedying of any defects.

1.1.5.8“工程”指永久工程和临时工程,或视情况指其中之一。

1.1.5.8 "Works" mean the Permanent Works and the Temporary Works, or either of them as appropriate.

1.1.6 其它定义

1.1.6 Other Definitions

1.1.6.1“承包商的文件”指由承包商按照合同规定提交的计算书、计算机程序及其它软件、图纸、手册、模型、和其它技术性文件(如有时)。

1.1.6.1 "Contractor's

1.1.6.2“工程所在国”指现场(或大部分现场)所在的国家,永久工程将在此实施。

1.1.6.2 "Country" means the country in which the Site (or most of it) is located, where the Permanent Works are to be executed.

1.1.6.3“雇主的设备”指规范中说明的,在实施工程的过程中,雇主提供给承包商使用的机械、仪器和车辆(如有时);但不包括尚未被雇主接收的永久设备。

1.1.6.3 "Employer's Equipment" means the apparatus, machinery and vehicles (if any) made available by the Employer for the use of the Contractor in the execution of the Works, as stated in the Specification; but does not include Plant which has not been taken over by the Employer.

1.1.6.4“不可抗力”如第19条【不可抗力】中所定义。

1.1.6.4 "Force Majeure" is defined in Clause 19 [Force Majeure]

1.1.6.5“法律”指所有国家(或州)的立法、法令、法规和其它法律、任何合法设立的政府机构的规章和章程。

1.1.6.5 "Laws" means all national (or state) legislation, statutes, ordinances and other laws, and regulations and by-laws of any legally constituted public authority.

1.1.6.6“履约保证”指第4.2款【履约保证】中的保证(可能有多份)。

1.1.6.6 "Performance Security" means the security (or securities, if any) under Sub-Clause 4.2 [Performance Security].

1.1.6.7“现场”指永久工程将要实施且永久设备和材料将运达的地点,及其它合同中规定为现场一部分的地点。

1.1.6.7 "Site" means the places where the Permanent Works are to be executed and to which Plant and Materials are to be delivered, and any other places as may be specified in the Contract as forming part of the Site.

1.1.6.8“不可预见”指一个有经验的承包商在提交投标文件那天还不能合理预见的。

1.1.6.8 "Unforeseeable" means not reasonably foreseeable by an experienced contractor by the date for submission of the Tender.

1.1.6.9“变更”指按照第13条【变更和调整】被指示或批准作为变更的对工程的任何变动。

1.1.6.9 "Variation" means any change to the Works, which is instructed or approved as a variation under Clause 13 [Variations and Adjustments].

1.2 解释

Interpretation

在合同中,除非文中另有规定,否则:

In the Contract, except where the context requires otherwise:

(a)表示阳性、阴性或中性的词包括所有的性别;

(a)

(b)单数形式的词亦包括复数含义,复数形式的词亦包括单数含义;

(b)

(c)包括“同意”、“批准”或“协议”这些字眼的规定,要求将涉及的协议书面记录下来,且

(c)

(d)“书面的”或“书面地”指手写、打字、印刷或运用电子技术制做,并形成了永久性的记录。

(d) "written" or "in writing" means hand-written, type-written, printed or electronically made, and resulting in a permanent record.

解释本合同条件时,不应考虑旁注和其它标题。

The marginal words and other headings shall not be taken into consideration in the interpretation of these Conditions.

1.3 通讯联络

Communications

在合同条件中,无论何处述及发出或颁发批准、证书、同意、决定、通知和要求,这些通讯联络均应:

Wherever these Conditions provide for the giving or issuing of approvals, certificates, consents, determinations, notices and requests, these communications shall be:

(a)为书面的,且应派人面交并取得收据,或者邮寄,或由信使送达,或按投标函附录中所列通过经同意的电子传输系统传输;且

(a) in writing and delivered by hand (against receipt), sent by mail or courier, or transmitted using any of the agreed systems of electronic transmission as stated in the Appendix to Tender; and

(b)递交、邮寄或传输到投标函附录中规定的收件人地址。但是:

(b) delivered, sent or transmitted to the address for the recipient's communications as stated in the Appendix to Tender. However:

(i)如果收件人发出了更改地址的通知,其后的信件应投送到相应的地址;且

(i) if the recipient gives notice of another address, communications shall thereafter be delivered accordingly; and

(ii)如果收件人在要求批准或同意时没有另做说明,此批准或同意可送达发出要求的地址。(ii) if the recipient has not stated otherwise when requesting an approval or consent, it may be sent to the address from which the request was issued.

批准、证书、同意及决定不得被无理扣压或拖延。向一方颁发证书时,颁发者应向另一方送交一份复印件。当另一方或工程师向一方发出通知时,应向工程师或另一方送交一份复印件(视情况而定)。

Approvals, certificates, consents and determinations shall not be unreasonably withheld or delayed. When a certificate is issued to a Party, the certifier shall send a copy to the other Party. When a notice is issued to a Party, by the other Parry or the Engineer, a copy shall be sent to the Engineer or the other Party, as the case may be.

1.4 法律和语言

1.4 Law and Language

合同应受投标函附录中规定的国家(或其它管辖区域)的法律的制约。

The Contract shall be governed by the law of the country (or other jurisdiction) stated in the Appendix to Tender.

如果合同的任何部分使用一种以上语言编写,从而构成了不同的版本,则以投标函附录中规定的主导语言编写的版本优先。

If there are versions of any part of the Contract which are written in more than one language, the version which is in the ruling language stated in the Appendix to Tender shall prevail.

往来信函应使用投标函附录中规定的语言。如果投标函附录中没有规定,则往来信函应使用编写合同(或大部分合同)的语言。

The language for communications shall be that stated in the Appendix to Tender. If no language is stated there, the language for communications shall be the language in which the Contract (or most of it) is written.

1.5 文件的优先次序

1.5 Priority of documents

构成合同的各个文件应被视作互为说明的。为解释之目的,各文件的优先次序如下:

The documents forming the Contract are to be taken as mutually explanatory of one another. For the purposes of interpretation, the priority of the documents shall be in accordance with the following sequence:

(a)合同协议书(如有时),

(a) the Contract Agreement (if any),

(b)中标函,

(b) the Letter of Acceptance,

(c)投标函,

(c) the Letter of Tender,

(d)专用条件,

(d) the Particular Conditions,

(e)本通用条件

(e) these General Conditions,

(f)规范

(f) the Specification,

(g)图纸,和

(g) the Drawings, and

(h)资料表以及其它构成合同一部分的文件。

(h) the Schedules and any other documents forming part of the Contract.

如果在合同文件中发现任何含混或矛盾之处,工程师应颁发任何必要的澄清或指示。

If an ambiguity or discrepancy is found in the documents, the Engineer shall issue any necessary clarification or instruction.

1.6 合同协议书

1.6 Contract Agreement

除非双方另有协议,否则双方应在承包商收到中标函后的28天内签订合同协议书。合同协议书应以专用条件后所附的格式为基础。法律规定的与签订合同协议书有关的印花税和其它类似费用(如有时)应由雇主承担。

The Parties shall enter into a Contract Agreement within 28 days after the Contractor receives the Letter of Acceptance, unless they agree otherwise. The Contract Agreement shall be based upon the form annexed to the Particular Conditions. The costs of stamp duties and similar charges (if any) imposed by law in connection with entry into the Contract Agreement shall be borne by the Employer.

1.7 转让

1.7 Assignment

任一方都不得转让整个或部分合同或转让根据合同应得的利益或权益。但一方:

Neither Party shall assign the whole or any part of the Contract or any benefit or interest in or under the Contract. However, either Party:

(a)经另一方的事先同意可以转让整个或部分合同,决定权完全在于另一方,及

(a) may assign the whole or any part with the prior agreement of the other Party, at the sole discretion of such other Party, and

(b)可将其按照合同对任何到期或将到期的金额所享有的权利,以银行或金融机构作为受益人,作为抵押转让出去。

(b) may, as security in favour of a bank or financial institution, assign its right to any moneys due, or to become due, under the Contract.

1.8 文件的保管和提供

1.8 Care and Supply of documents

规范和图纸应由雇主保护和保管。除非合同另有规定,否则雇主应向承包商提供合同及每份后续图纸的两份复印件,承包商可自行复制或要求雇主为其提供更多的复印件,但费用自理。The Specification and Drawings shall be in the custody and care of the Employer. Unless otherwise stated in the Contract, two copies of the Contract and of each subsequent Drawing shall be supplied to the Contractor, who may make or request further copies at the cost of the Contractor.

在移交给雇主之前,每份承包商的文件都应由承包商来保护和保管。除非合同另有规定,否则承包商应向工程师提供6份承包商的所有文件的复印件。

Each of the Contractor's documents shall be in the custody and care of the Contractor, unless and until taken over by the Employer. Unless otherwise stated in the Contract, the Contractor shall supply to the Engineer six copies of each of the Contractor's documents.

承包商应在现场保留一份合同的复印件、规范中列出的所有文件、承包商的文件(如有时)、图纸和变更以及其它按照合同收发的往来信函。雇主的人员有权在任何合理的时间查看和使用所有上述文件。

The Contractor shall keep, on the Site, a copy of the Contract, publications named in the Specification, the Contractor's documents (if any), the Drawings and Variations and other communications given under the Contract. The Employer's Personnel shall have the right of access to all these documents at all reasonable times.

如果一方在用于施工的文件中发现了技术性错误或缺陷,应立即向另一方通知此类错误或缺陷。

If a Party becomes aware of an error or defect of a technical nature in a document which was prepared for use in executing the Works, the Party shall promptly give notice to the other Party of such error or defect.

1.9 拖延的图纸或指示

1.9 Delayed Drawings or Instructions

当因必要的图纸或指示不能在一合理的特定时间内颁发给承包商,从而可能引起工程延误或中断时,承包商应通知工程师。通知中应包括所必需的图纸或指示的详细内容、应颁发的详细理由和时间,以及如果因图纸或指示迟发可能造成的延误或中断的具体性质和程度。The Contractor shall give notice to the Engineer whenever the Works are likely to be delayed or disrupted if any necessary drawing or instruction is not issued to the Contractor within a particular time, which shall be reasonable. The notice shall include details of the necessary drawing or instruction, details of why and by when it should be issued, and details of the nature and amount of the delay or disruption likely to be suffered if it is late.

如果因工程师未能在一合理的、且已在(附有详细证据的)通知中说明的时间内颁发承包商在通知中要求的图纸或指示,而导致承包商延误和(/或)招致费用增加时,承包商应向工程师发出进一步的通知,且按照第20.1款【承包商的索赔】有权获得:

If the Contractor suffers delay and/or incurs Cost as a result of a failure of the Engineer to issue the notified drawing or instruction within a time which is reasonable and is specified in the notice with supporting details, the Contractor shall give a further notice to the Engineer and shall be entitled subject to Sub-Clause 20.1 [Contractor's Claims] to:

(a)根据第8.4款【竣工时间的延长】对任何此类延误的一段延期,如果竣工被拖延或将被拖延;及

(a)an extension of time for any such delay, if completion is or will be delayed, under Sub-Clause 8.4 [Extension of Time for Completion], and

(b)对此费用加上合理利润的支付,此支付应包括在合同价中。

(b)payment of any such Cost plus reasonable profit, which shall be included in the Contract Price.

收到上述进一步的通知后,工程师应按照第3.5款【决定】对这些事项表示批准或作出决定。

After receiving this further notice, the Engineer shall proceed in accordance with Sub Clause 3.5 [Determinations] to agree or determine these matters.

但是,如果工程师未能及时提供图纸或指示是由承包商的错误或延误(包括递交承包商的文件时的错误和延误)引起的,则承包商无权获得上述延期、费用或利润。

However, if and to the extent that the Engineer's failure was caused by any error or delay by the Contractor, including an error in, or delay in the submission of, any of the Contractor's documents, the Contractor shall not be entitled to such extension of time, Cost or profit.

1.10 雇主使用承包商的文件

1.10 Employer's Use of Contractor's documents

在合同双方之间,承包商应对承包商的文件和其它由承包商(或承包商授权的人员)编制的设计文件保留版权和其它知识产权。

As between the Parties 'the Contractor shall retain the copyright and other intellectual property rights in the Contractor's documents and other design documents made by (or on behalf of) the Contractor

应认为承包商通过签订合同给予了雇主复印、使用及传输(包括修改和使用对其的修改)承包商的文件的免费使用的许可证,此许可证是无限期的、可转让且非专用的。此许可证应:The Contractor shall be deemed (by signing the Contract) to give to the Employer a non-terminable transferable non-exclusive royalty-free licence to copy, use and communicate the Contractor's documents, including making and using modifications of them. This licence shall:

(a)在工程各有关部分的实际或预期工作期(取较长者)内有效,

(a)apply throughout the actual or intended working life (whichever is longer) of the relevant parts of the Works,

(b)使任何合法拥有工程有关部分的当事人为完成、操作、维护、改变、调整、修理和拆除工程之目的,复印、使用、传输承包商的文件,且

(b)entitle any person in proper possession of the relevant part of the Works to copy, use and communicate the Contractor's documents for the purposes of completing, operating, maintaining, altering, adjusting, repairing and demolishing the Works, and

(c)在承包商的文件采用计算机程序和其它软件形式的情况下,允许其在置于现场及其它合同中许可的地点的计算机(包括由承包商提供的代用计算机)上使用。

(c)in the case of Contractor's documents which are in the form of computer programs and other software, permit their use on any computer on the Site and other places as envisaged by the Contract, including replacements of any computers supplied by the Contractor.

未经承包商同意,雇主不得因本款规定外的任何目的为第三方复印、使用或传输承包商的文件及其它任何由承包商(或承包商授权的人员)编制的设计文件。

The Contractor's documents and other design documents made by (or on behalf of) the Contractor shall not, without the Contractor's consent, be used, copied or communicated to a third party by (or on behalf of) the Employer for purposes other than those permitted under this Sub-Clause.

1.11 承包商使用雇主的文件

1.11 Contractor's Use of Employer's documents

在合同双方之间,雇主应对规范、图纸和其它由雇主(或雇主授权的人员)编制的设计文件保留版权和其它知识产权。承包商可为合同之目的,自费复印、使用、及传输上述文件。除非因履行合同而必需,否则不经雇主同意,承包商不得为第三方复印、使用、或传输上述文件。As between the Parties, the Employer shall retain the copyright and other intellectual property rights in the Specification, the Drawings and other documents made by (or on behalf of) the Employer. The Contractor may, at his cost, copy, use, and obtain communication of these documents for the purposes of the Contract. They shall not, without the Employer's consent, be copied, used or communicated to a third party by the Contractor, except as necessary for the purposes of the Contract.

1.12 保密事项

1.12 Confidential Details

为证实承包商是否遵守合同,他应按照工程师的合理要求透露其要求的保密事项和其它情况。

The Contractor shall disclose all such confidential and other information as the Engineer may reasonably require in order to verify the Contractor's compliance with the Contract.

1.13 遵守法律

1.13 Compliance with Laws

除非在专用条件中另有说明,履行合同时,承包商应遵守适用的法律的规定:

The Contractor shall, in performing the Contract, comply with applicable Laws. Unless otherwise sated in the Particular conditions:

(a)雇主应已经(或将要)获得永久工程的规划、分区和其它类似许可,及规范中说明已经(或将要)由雇主取得的其它许可;雇主应保障承包商不受其未得到上述许可的后果的侵害;且

(a)the Employer shall have obtained (or shall obtain) the planning, zoning or similar permission for the Permanent Works, and any other permissions described in the Specification as having been (or being) obtained by the Employer; and the Employer shall indemnify and hold the Contractor harmless against and from the consequences of any failure to do so; and

(b)对于法律中要求的与实施、完成工程和修补缺陷有关的各项事宜,应由承包商发出通知、支付税款、关税和费用,并获得所有的许可、许可证和批准;承包商应保障雇主免遭其未做到上述要求的后果的损失。

(b)the Contractor shall give all notices, pay all taxes, duties and fees, and obtain all permits, licences and approvals, as required by the Laws in relation to the execution and completion of the Works and the remedying of any defects; and the Contractor shall indemnify and hold the Employer harmless against and from the consequences of any failure to do so.

1.14 共同的与各自的责任

1.14 Joint and Several Liability

如果承包商是由两个或两个以上当事人组成的联营体、联合集团或其它联合团体时:

If the Contractor constitutes (under applicable Laws) a joint venture, consortium or other unincorporated grouping of two or more persons:

(a)应认为上述当事人应向雇主对合同的履行负共同的与各自的责任;

(a)these persons shall be deemed to be jointly and severally liable to the Employer

for the performance of the Contract;

(b)上述当事人应向雇主通知他们的负责人,此负责人有权管理承包商及其中每位成员;且

(b)these persons shall notify the Employer of their leader who shall have authority to bind the Contractor and each of these persons; and

没有雇主的事先同意,承包商不得改变其组成或法律地位。

(c)the Contractor shall not alter its composition or legal status without the prior consent of the Employer.

2.雇主

THE EMPLOYER

2.1 进入现场的权利

2.1 Right of Access to the Site

雇主应在投标函附录中注明的时间(或各时间段)内给予承包商进入和占用现场所有部分的权利。此类进入和占用权可不为承包商独享。如果合同要求雇主赋予(承包商)对基础、结构、永久设备或通行手段的占用权,则雇主应在规范注明的时间内按照规范中规定的方式履行该职责。但是在收到履约保证之前,雇主可以不给予任何此类权利或占用。

The Employer shall give the Contractor right of access to, and possession of, all parts of the Site within the time (or times) stated in the Appendix to Tender. The right and possession may not be exclusive to the Contractor. If, under the Contract, the Employer is required to give (to the Contractor) possession of any foundation, structure, plant or means of access, the Employer shall do so in the time and manner stated in the Specification. However, the Employer may withhold any such right or possession until the Performance Security has been received.

如果投标函附录中未注明时间,则雇主应在一合理的时间内给予承包商进入现场和占用现场的权利,此时间应能使承包商可以按照第8.3款【进度计划】提交的进度计划顺利开始施工。If no such time is stated in the Appendix to Tender, the Employer shall give the Contractor right of access to, and possession of, the Site within such times as may be required to enable the Contractor to proceed in accordance with the programme submitted under Sub-Clause 8.3 [Programme].

如果由于雇主一方未能在规定时间内给予承包商进入现场和占用现场的权利,致使承包商延误了工期和(或)增加了费用,承包商应向工程师发出通知,并依据第20.1款【承包商的索赔】有权:

If the Contractor suffers delay and/or incurs Cost as a result of a failure by the Employer to give any such right or possession within such time, the Contractor shall give notice to the Engineer and shall be entitled subject to Sub-Clause 20.1 [Contractor's Claims] to:

(a) 如果竣工已经或将被延误,根据第8.4款【竣工时间的延长】的规定,对所有此类延误获得延长的工期,;以及

(a) an extension of time for any such, delay, if completion is or will be delayed, under Sub-Clause 8.4 [Extension of Time for Completion], and

(b) 获得任何有关费用加上合理利润的支付,并将之加入合同价格。

(b) payment of any such Cost plus reasonable profit, which shall be included in the Contract Price.

在收到此通知后,工程师应按照第3.5款【决定】对此事作出商定或决定。

After receiving this notice, the Engineer shall proceed in accordance with Sub Clause 3.5 [Determinations] to agree or determine these matters.

然而,如果雇主的过失(并且在一定程度上)是由于承包商的某些错误或延误造成的,包括承包商的文件中的错误或提交的延误,则承包商无权要求获得此类延长的工期、费用或利润。However, if and to the extent that the Employer's failure was caused by any error or delay by the Contractor, including an error in, or delay in the submission of, any of the Contractor's documents, the Contractor shall not be entitled to such extension of time, Cost or profit.

2.2 许可、执照和批准

2.2 Permits, Licences or Approval

雇主应根据承包商的请求,为以下事宜向承包商提供合理的协助(如果他的地位能够做到),以帮助承包商:

The Employer shall (where he is in a position to do so) provide reasonable assistance to the Contractor at the request of the Contractor:

(a) 获得与合同有关的但不易取得的工程所在国的法律的副本,以及

(a) by obtaining copies of the Laws of the Country which are relevant to the Contract but are not readily available, and

(b) 申请法律所要求的许可、执照或批准,包括

(b) for the Contractor's applications for any permits, licences or approvals required by the Laws of the Country:

(i) 依据第1.13款【遵守法律】要求承包商必须获得的,

(i)which the Contractor is required to obtain under Sub-Clause 1.13 [Compliance with Laws],

(ii) 为了货物的运送,包括清关所需的,以及

(ii)for the delivery of Goods, including clearance through customs, and

(iii) 当承包商的设备运离现场而出口时所需的。

(iii)for the export of Contractor's Equipment when it is removed from the

2.3 雇主的人员

2.3 Employer's Personnel

雇主有责任保证现场的雇主的人员和雇主的其他承包商:

The Employer shall be responsible for ensuring that the Employer's Personnel and the Employer's other contractors on the Site:

(a) 依照第4.6款【合作】为承包商的工作提供合作,以及

(a) co-operate with the Contractor's efforts under Sub-Clause 4.6 [Co-operation], and

(b) 采取类似于承包商按照第4.8款【安全措施】(a)、(b)和(c)段和第4.18款【环境保护】的要求而应采取的措施。

(b) take actions similar to those which the Contractor is required to take under subparagraphs (a), (b) and (c) of Sub-Clause 4.8 [Safety Procedures] and under Sub-Clause 4.18 [Protection of the Environment].

2.4 雇主的资金安排

2.4 Employer's Financial Arrangements

在接到承包商的请求后,雇主应在28天内提供合理的证据,表明他已作出了资金安排,并将一直坚持实施这种安排,此安排能够使雇主按照第14条【合同价格和支付】的规定支付

合同价格(按照当时的估算值)的款额。如果雇主欲对其资金安排做出任何实质性变更,雇主应向承包商发出通知并提供详细资料。

The Employer shall submit. within 28 days after receiving any request from the Contractor, reasonable evidence that financial arrangements have been made and are being maintained which will enable the Employer to pay the Contract Price (as estimated at that time) in accordance with Clause 14 [Contract Price and Payment]. If the Employer intends to make any material change to his financial arrangements, the Employer shall give notice to the Contractor with detailed particulars.

2.5 雇主的索赔

2.5 Employer's Claims

如果雇主认为按照任何合同条件或其它与合同有关的条款规定他有权获得支付和(或)缺陷通知期的延长,则雇主或工程师应向承包商发出通知并说明细节。但对于按照第4.19款【电、水、气】、第4.20款【雇主的设备及免费提供的材料】的规定,承包商应支付的款额或其它因承包商要求某些服务而应支付的款额,则无须发出通知。

If the Employer considers himself to be entitled to any payment under any Clause of these Conditions or otherwise in connection with the Contract, and/or to any extension of the Defects Notification Period, the Employer or the Engineer shall give notice and particulars to the Contractor. However, notice is not required for payments due under Sub-Clause 4.19 [Electricity, Water and Gas], under Sub-Clause 4.20 [Employer's Equipment and Free-Issue Material], or

当雇主意识到某事件或情况可能导致索赔时应尽快地发出通知。涉及任何延期的通知应在相关缺陷通知期期满前发出。

The notice shall be given as soon as practicable after the Employer became aware of the event or circumstances giving rise to the claim. A notice relating to any extension of the Defects Notification Period shall be given before the expiry of such

在细节中应详细说明索赔条款或其它依据,包括雇主按照合同认为他自己有权获得的费用和(或)延期的证明,工程师应依据第3.5款【决定】作出商定或决定:(i) 雇主有权获得的由承包商支付的款额(如有时),以及/或 (ii) 依据第11.3款【缺陷通知期的延长】给予缺陷通知期的延长(如有时)。

The particulars shall specify the Clause or other basis of the claim, and shall include substantiation of the amount and/or extension to which the Employer consider: himself to be entitled in connection with the Contract. The Engineer shall then proceed in accordance with Sub-Clause 3.5 [Determinations] to agree or determine (i) the amount (if any) which the Employer is entitled to be paid by the Contractor, and/o(ii) the extension (if any) of the Defects Notification Period in accordance with Sub Clause 11.3 [Extension of Defects Notification Period].

此笔款额应在合同价格及支付证书中扣除。雇主仅有权从支付证书中确定的款额中抵消或扣除,或依据本款向承包商另外提出索赔。

This amount may be included as a deduction in the Contract Price and Payment Certificates. The Employer shall only be entitled to set off against or make any deduction from an amount certified in a Payment Certificate, or to otherwise claim against the Contractor, in accordance with this Sub-Clause.

3.工程师

THE ENGINEER

3.1 工程师的职责和权力

3.1Engineer's Duties and Authority

雇主应任命工程师,该工程师应履行合同中赋予他的职责。工程师的人员包括有恰当资格的工程师以及其他有能力履行上述职责的专业人员。

The Employer shall appoint the Engineer who shall carry out the duties assigned to Authority him in the Contract. The Engineer's staff shall include suitably qualified engineers and other professionals who are competent to carry out these duties. 工程师无权修改合同。

The Engineer shall have no authority to amend the Contract.

工程师可行使合同中明确规定的或必然隐含的赋予他的权力。如果要求工程师在行使其规定权力之前需获得雇主的批准,则此类要求应与合同专用条件中注明。雇主不能对工程师的权力加以进一步限制,除非与承包商达成一致。

The Engineer may exercise the authority attributable to the Engineer as specified in or necessarily to be implied from the Contract. If the Engineer is required to obtain the approval of the Employer before exercising a specified authority, the requirements shall be as stated in the Particular Conditions. The Employer undertakes not to impose further constraints on the Engineer's authority, except as agreed with the Contractor.

然而,每当工程师行使某种需经雇主批准的权力时,则被认为他已从雇主处得到任何必要的批准(为合同之目的)。

However, whenever the Engineer exercises a specified authority for which the Employer's approval is required, then (for the purposes of the Contract) the Employer shall be deemed to have given approval.

除非合同条件中另有说明,否则:

Except as otherwise stated in these Conditions:

(a) 当履行职责或行使合同中明确规定的或必然隐含的权力时,均认为工程师为雇主工作。whenever carrying out duties or exercising authority, specified in or implied by the Contract, the Engineer shall be deemed to act for the Employer;

(b) 工程师无权解除任何一方依照合同具有的任何职责、义务或责任,以及

the Engineer has no authority to relieve either Party of any duties, obligations or responsibilities under the Contract; and

(c) 工程师的任何批准、审查、证书、同意、审核、检查、指示、通知、建议、请求、检验或类似行为(包括没有否定),不能解除承包商依照合同应具有的任何责任,包括对其错误、漏项、误差以及未能遵守合同的责任。

any approval, check, certificate, consent, examination, inspection, instruction, notice, proposal, request, test, or similar act by the Engineer (including absence of disapproval) shall not relieve the Contractor from any responsibility he has under the Contract, including responsibility for errors, omissions, discrepancies and non-compliances.

3.2 工程师的授权

3.2 Delegation by the Engineer

工程师可以随时将他的职责和权力委托给助理,并可撤回此类委托或授权。这些助理包括现场工程师和(或)指定的对设备和(或)材料进行检查和(或)检验的独立检查人员。此类

委托、授权或撤回应是书面的并且在合同双方接到副本之前不能生效。但是工程师不能授予其按照第3.5款【决定】的规定决定任何事项的权力,除非合同双方另有协议。

The Engineer may from time to time assign duties and delegate authority to assistants, and may also revoke such assignment or delegation. These assistants may include a resident engineer, and/or independent inspectors appointed to inspect and/or test items of Plant and/or Materials. The assignment, delegation or revocation shall be in writing and shall not take effect until copies have been received by both Parties. However, unless otherwise agreed by both Parties, the Engineer shall not delegate the authority to determine any matter in accordance with Sub-Clause 3.5 [Determinations].

助理必须是合适的合格人员,有能力履行这些职责以及行使这种权力,并且能够流利地使用第1.4款【法律和语言】中规定的语言进行交流。

Assistants shall be suitably qualified persons, who are competent to carry out these duties and exercise this authority, and who are fluent in the language for communications defined in Sub-Clause 1.4 [Law and Language].

被委托职责或授予权力的每个助理只有权力在其被授权范围内对承包商发布指示。由助理按照授权作出的任何批准、审查、证书、同意、审核、检查、指示、通知、建议、请求、检验或类似行为,应与工程师作出的具有同等的效力。但:

Each assistant, to whom duties have been assigned or authority has been delegated, shall only be authorised to issue instructions to the Contractor to the extent defined by the delegation. Any approval, check, certificate, consent, examination, inspection, instruction, notice, proposal, request, test, or similar act by an assistant, in accordance with the delegation, shall have the same effect as though the act had been an act of the Engineer. However:

(a) 未对任何工作、永久设备及材料提出否定意见并不构成批准,也不影响工程师拒绝该工作、永久设备及材料的权利;

(a) any failure to disapprove any work, Plant or Materials shall not constitute approval, and shall therefore not prejudice the right of the Engineer to reject the work, Plant or Materials;

(b) 如果承包商对助理的任何决定或指示提出质疑,承包商可将此情况提交工程师,工程师应尽快对此类决定或指示加以确认、否定或更改。

(b) if the Contractor questions any determination or instruction of an assistant, the Contractor may refer the matter to the Engineer, who shall promptly confirm, reverse or vary the determination or instruction.

3.3 工程师的指示

3.3 Instructions of the Engineer

工程师可以按照合同的规定(在任何时候)向承包商发出指示以及为实施工程和修补缺陷所必需的附加的或修改的图纸。承包商只能从工程师以及按照本条款授权的助理处接受指示。如果某一指示构成了变更,则适用于第13条【变更和调整】。

The Engineer may issue to the Contractor (at any time) instructions and additional or modified Drawings which may be necessary for the execution of the Works and the remedying of any defects, all in accordance with the Contract. The Contractor shall only take instructions from the Engineer, or from an assistant to whom the appropriate authority has been delegated under this Clause. If an instruction

constitutes a Variation, Clause 13 (Variations and Adjustments) shall apply.

承包商必须遵守工程师或授权助理对有关合同的某些问题所发出的指示。只要有可能,这些指示均应是书面的。如果工程师或授权助理:

The Contractor shall comply with the instructions given by the Engineer or delegated assistant, on any matter related to the Contract. Whenever practicable, their instructions shall be given in writing. If the Engineer or a delegated assistant: (a) 发出一口头指示;

(a) gives an oral instruction,

(b) 在发出指示后2个工作日内,从承包商(或承包商授权的他人)处接到指示的书面确认;以及

(b) receives a written confirmation of the instruction, from (or on behalf of) the Contractor, within two working days after giving the instruction, and

(c) 在接到确认后2个工作日内未颁发一书面拒绝和(或)指示作为回复,

(c) does not reply by issuing a written rejection and/or instruction within two working days after receiving the confirmation,

则此确认构成工程师或授权助理的书面指示(视情况而定)。

then the confirmation shall constitute the written instruction of the Engineer or delegated assistant (as the case may be).

3.4 工程师的撤换

3.4 Replacement of the Engineer

如果雇主准备撤换工程师,则必须在期望撤换日期42天以前向承包商发出通知说明拟替换的工程师的名称、地址及相关经历。如果承包商对替换人选向雇主发出了拒绝通知,并附具体的证明资料,则雇主不能撤换工程师。

If the Employer intends to replace the Engineer, the Employer shall, not less than 42 days before the intended date of replacement, give notice to the Contractor of the name, address and relevant experience of the intended replacement Engineer. The Employer shall not replace the Engineer with a person against whom the Contractor raises reasonable objection by notice to the Employer, with supporting particulars.

3.5 决定

3.5 Determinations

每当合同条件要求工程师按照本款规定对某一事项作出商定或决定时,工程师应与合同双方协商并尽力达成一致。如果未能达成一致,工程师应按照合同规定在适当考虑到所有有关情况后作出公正的决定。

Whenever these Conditions provide that the Engineer shall proceed in accordance with this Sub-Clause 3.5 to agree or determine any matter, the Engineer shall consult with each Party in an endeavour to reach agreement. If agreement is not achieved, the Engineer shall make a fair determination in accordance with the Contract, taking due regard of all relevant circumstances.

工程师应将每一项协议或决定向每一方发出通知以及具体的证明资料。每一方均应遵守该协议或决定,除非和直到按照第20条【索赔、争端和仲裁】规定作出了修改。

The Engineer shall give notice to both Parties of each agreement or determination, with supporting particulars. Each Party shall give effect to each agreement or determination unless and until revised under Clause 20 [Claims, Disputes and Arbitration].

4.承包商

The Contractor

4.1 承包商的一般义务

4.1 Contractor's General Obligations

承包商应按照合同的规定以及工程师的指示(在合同规定的范围内)对工程进行设计、施工和竣工,并修补其任何缺陷。

The Contractor shall design (to the extent specified in the Contract), execute and complete the Works in accordance with the Contract and with the Engineer's instructions, and shall remedy any defects in the Works.

承包商应为工程的设计、施工、竣工以及修补缺陷提供所需的临时性或永久性的永久设备、合同中注明的承包商的文件、所有承包商的人员、货物、消耗品以及其他物品或服务。

The Contractor shall provide the Plant and Contractor's documents specified in the Contract, and all Contractor's Personnel, Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for this design, execution, completion and remedying of defects.

承包商应对所有现场作业和施工方法的完备性、稳定性和安全性负责。除合同中规定的范围,承包商(i)应对所有承包商的文件、临时工程和按照合同规定对每项永久设备和材料的所做的设计负责;以及(ii)但对永久工程的设计或规范不负责任。

The Contractor shall be responsible for the adequacy, stability and safety of all Site operations and of all methods of construction. Except to the extent specified in the Contract, the Contractor (i) shall be responsible for all Contractor's documents, Temporary Works, and such design of each item of Plant and Materials as is required for the item to be in accordance with the Contract, and (ii) shall not otherwise be responsible for the design or specification of the Permanent Works. 在工程师的要求下,承包商应提交为实施工程拟采用的方法以及所作安排的详细说明。在事先未通知工程师的情况下,不得对此类安排和方法进行重大修改。

The Contractor shall, whenever required by the Engineer, submit details of the arrangements and methods which the Contractor proposes to adopt for the execution of the Works. No significant alteration to these arrangements and methods shall be made without this having previously been notified to the Engineer.

如果合同中明确规定由承包商设计部分永久工程,除非专用条件中另有规定,否则:

If the Contract specifies that the Contractor shall design any part of the Permanent Works, then unless otherwise stated in the Particular Conditions:

(a) 承包商应按照合同中说明的程序向工程师提交该部分工程的承包商的文件;

(a) the Contractor shall submit to the Engineer the Contractor's documents for this part in accordance with the procedures specified in the Contract;

(b) 承包商的文件必须符合规范和图纸,并使用第1.4款【法律和语言】规定的交流语言,还应包括工程师要求的为统一各方设计而应加入图纸中的附加信息;

(b) these Contractor's documents shall be in accordance with the Specification and Drawings, shall be written in the language for communications defined in Sub-Clause 1.4 [Law and Language], and shall include additional information required by the Engineer to add to the, Drawings for co-ordination of each Party's designs; (c) 承包商应对该部分工程负责,并且该部分工程完工后应适合于合同中规定的工程的预期目的;以及

(c) the Contractor shall be responsible for this part and it shall, when the Works are completed, be fit for such purposes for which the part is intended as are specified in the Contract; and

(d) 在开始竣工检验之前,承包商应按照规范规定向工程师提交竣工文件以及操作和维修手册,且应足够详细,以使雇主能够操作、维修、拆卸、重新安装、调整和修理该部分工程。在将此类文件和手册提交工程师之前,依据第10.1款【对工程和区段的接收】的规定,不得认为为接收之目的该部分工程业已完成。

(d) prior to the commencement of the Tests on Completion, the Contractor shall submit to the Engineer the "as-built" documents and operation and maintenance manuals in accordance with the Specification and in sufficient detail for the Employer to operate, maintain, dismantle, reassemble, adjust and repair this part of the Works. Such part shall not be considered to be completed for the purposes of taking-over under Sub-Clause 10.1 [Taking Over of the Works and Sections] until these documents and manuals have been submitted to the Engineer.

4.2 履约保证

4.2 Performance Security

承包商应(自费)取得一份保证其恰当履约的履约保证,保证的金额和货币种类应与投标函附录中的规定一致。如果投标函附录中未说明金额,则本款不适用。

The Contractor shall obtain (at his cost) a Performance Security for proper performance, in the amount and currencies stated in the Appendix to Tender. If an amount is not stated in the Appendix to Tender, this Sub-Clause shall not apply. 承包商应在收到中标函后28天内将此履约保证提交给雇主,并向工程师提交一份副本。该保证应在雇主批准的实体和国家(或其它管辖区)管辖范围内颁发,并采用专用条件附件中规定的格式或雇主批准的其他格式。

The Contractor shall deliver the Performance Security to the. Employer within 28 days after receiving the Letter of Acceptance, and shall send a copy to the Engineer. The Performance Security shall be issued by an entity and from within a country (or other jurisdiction) approved by the Employer, and shall be in the form annexed to the Particular Conditions or in another form approved by the Employer.

在承包商完成工程和竣工并修补任何缺陷之前,承包商应保证履约保证将持续有效。如果该保证的条款明确说明了其期满日期,而且承包商在此期满日期前第28天还无权收回此履约保证,则承包商应相应延长履约保证的有效期,直至工程竣工并修补了缺陷。

The Contractor shall ensure that the Performance Security is valid and enforceable until the Contractor has executed and completed the Works and remedied any defects. If the terms of the Performance Security specify its expiry date, and the Contractor has not become entitled to receive the Performance Certificate by the date 28 days prior to the expiry date, the Contractor shall extend the validity of the Performance Security until the Works have been completed and any defects have been remedied. 雇主不能按照履约保证提出索赔,但以下按照合同雇主有权获得款额的情况除外:

The Employer shall not make a claim under the Performance Security, except for amounts to which the Employer is entitled under the Contract in the event of: (a) 承包商未能按照上一段的说明,延长履约保证的有效期,此时雇主可对履约保证的全部金额进行索赔,

(a) failure by the Contractor to extend the validity of the Performance Security

中英文自荐信范文

中英文自荐信范文 第一篇:中英文-自荐信dear sir, professor kenneth h. chan, head of the department of metallurgy, has informed me that your agency is looking for an engineering graduate with the ability to write about technical subjects for non-technical readers. the four years at hong kong university have given me a thorough foundation in such fundamental sciences as physics, mathematics, and chemistry, in addition to specialized courses in metallurgy. i have also taken as many courses in english and psychology as possible with the expectation that i would enter the field of technical sales or editing following my graduation this summer. fortunately, as my resume shows, i now have a mature interest in finding a satisfying job. may i come in for an interview at your convenience? sincerely yours, 敬啟者: 冶金系主任陈教授告诉我,贵公司在物色有能力写专门性文章给一般读者阅读的工科毕业生。 在香港大学四年我奠定了冶金及物理、数学、化学基本科学的良好基础。我曾经选修许多门英语和心理学方面的课程,期望今年夏天

Fidic 红皮书主要名词中英文对照

1.General Provisions一般规定 Contract 合同 Contract Agreement 合同协议书1.6 Letter of Acceptance 中标函1.1.3 (a. 业主对承包商正式接受函,签字;b.双方商定的其他内容,双方签字) Letter of Tender 投标函(承包商的报价函) Specification 规范 Drawings 图纸 Schedules 明细表 Tender 投标书(a. 投标函;b. 投标者填写的各类明细表,投标保函等) Appendix to Tender 投标函附录 Bill of Quantities 工程量表 Daywork Schedule 计日工表 Parties and Persons 合同双方和人员 Engineer 工程师(natural/legal)(监理) DAB 争端裁决委员会(投标函附录列出) FIDIC 国际咨询工程联合会(International Federation of Consulting Engineers) Dates 日期Tests 检验Periods 期间Completion 竣工 Base Date 基准日期(提交投标书截止日期之前的第28天当天;与调价有关)Commencement Date 开工日期(工程师通知开工的日期) Time for Completion 竣工日期(指时间段,从开工日期开始计算) Tests on Completion 竣工检验 Taking-over Certificate 接收证书(证明工程按照合同实质竣工,进入缺陷通知期) Tests after Completion 竣工后检验 Defects Notification Period 缺陷通知期维修期 Performance Certificate 履约证书 Money and Payments 款项和支付 Accepted Contract Amount 中标合同金额(中标的承包商的投标价格,名义合同价格)Contract Prise 合同价格(a. b.包含根据合同进行的调整) Cost 费用(承包商现场内外全部合理开支,不包括利润) Final Payment Certificate 最终支付证书(承包商将从业主方拿到的最后的一笔工程款) Final Statement 最终报表 Foreign Currency 外币 Interim Payment Certificate 期中支付证书 Local Curency 当地币 Payment Certificate 支付证书(期中和最终) Provisional Sum暂定金额(相当于业主方的备用金)13.5 /14.2 Retention Money 保留金(现金保证金,保证承包商在工程的执行的过程中恰当履约)14.3/14.9 Statement 报表(完成工程量的合同价值及其他相关情况月报竣工报表最终报表) Works and Goods 工程和货物(eg. 材料,永久设备,施工机具…完成的工程火或其一部分)Contractor’s Equipment 承包商设备(承包商的施工机具) Goods 货物 Materials 材料 Permanent Works 永久工程

最新中英文自荐信范文

中英文自荐信范文 第1篇第2篇第3篇第4篇第5篇更多顶部 目录 第一篇:中英文-自荐信第二篇:中英文自荐信四第三篇:中英文自荐信五第四篇:个人简历中英文自荐信第五篇:医药学毕业中英文自荐信更多相关范文 正文第一篇:中英文-自荐信dear sir, professor kenneth h. chan, head of the department of metallurgy, has informed me that your agency is looking for an engineering graduate e a thorough foundation in such fundamental sciences as physics, mathematics, and chemistry, in addition to specialized courses in metallurgy. i have also taken as many courses in english and psychology as possible y graduation this summer. fortunately, as my resume shoature interest in finding a satisfying job. may i come in for an intervie the university of kansas asters degree in june of this year. my major is pharmacy and i am very interested in securing a position before i graduate, if possible. i am a hong kong chinese and my bachelor’s degree is

FIDIC新红皮书全文

FIDIC 施工合同条件 (1999年第一版) 用于业主设计的房屋建筑或工程 通用条件 专用条件编制指南 争端裁决协议书格式 投标函、合同协议书格式 周可荣刘雯 万彩芸王健译 说明:因时间较紧,本译稿未经仔细校对,仅供培训班使用,请勿复印传播。请勿正式引用。

引言 国际咨询工程师联合会(FIDIC)现于1999年出版下列四份新的合同标准格式的第一版: ●施工合同条件(Conditions of Contract for Construction) 推荐用于由雇主设计的、或由其代表—工程师设计的房屋建筑或工程(building or engineering works)。在这种合同形式下,承包商一般都按照雇主提供的设计施工。但工程中的某些土木、机械、电力和/或建造工程也可能由承包商设计。 ●永久设备和设计—建造合同条件(Conditions of Contract for Plant and Design-Build) 推荐用于电力和/或机械设备的提供,以及房屋建筑或工程的设计和实施。在这种合同形式下,一般都是由承包商按照雇主的要求设计和提供设备和/或其它工程(可能包括由土木、机械、电力、和/或建造工程的任何组合形式)。 ●EPC/交钥匙项目合同条件(Conditions of Contract for EPC/Turnkey Projects) 适用于在交钥匙的基础上进行的工厂或其它类似设施的加工或能源设备的提供、或基础设施项目和其它类型的开发项目的实施,这种合同条件所适用的项目(i)对最终价格和施工时间的确定性要求较高,(ii)承包商完全负责项目的设计和施工,雇主基本不参与工作。 在交钥匙项目中,一般情况下由承包商实施所有的设计、采购和建造工作:即在“交钥匙”时,提供一个配备完整、可以运行的设施。 ●合同的简短格式(Short Form of Contract) 推荐用于价值相对较低的建筑或工程。根据工程的类型和具体条件的不同,此格式也适用于价值较高的工程,特别是较简单的、或重复性的、或工期短的工程。在这种合同形式下,一般都是由承包商按照雇主或其代表—工程师提供的设计实施工程,但对于部分或完全由承包商设计的土木、机械、电力、和/或建造工程的合同也同样适用。 建议在国际范围内招标时使用上述格式作为合同基础。在某些国家和地区,特别是当合同条件用于其国内合同时,可能需要对这些格式进行一些改动。FIDIC是按照以英语为官方语言的情况编写的。 在编写本施工合同条件的过程中我们认识到,有许多条款是普遍适用的,但也有一些条款必须根据特定合同的具体情况予以变动。因此,我们将那些对大多数(并非全部)合同都适用的条款编入了通用条件中,以方便使用者将其纳入合同文件。 通用条件和专用条件共同构成了制约合同各方权力和义务的条件。对于每一份具体的合同,都必须编制专用条件,并且必须考虑到通用条件中提到的专用条件中的条款。 本版的通用条件是基于下列情况编写的: (i)期中支付和最终支付将按照测量的数值乘以工程量表中的费率和价格决定; (ii)如果通用条件中的某些词语需要用进一步的数据来说明,那么(除非其描述性很强,因而必须在规范中详细说明外)要参照此数据的条款应编入投标文件 附录中,数据由雇主事先写明或由投标者填入; (iii)如果通用条件中的某条款涉及某一事件,而对此事件不同的合同可能适于采用不同的合同格式,则编写此条款的原则应为; (a)要使用户感到,简单地删去或不引用某些他们不希望采用的规定,比在通用条件中没有包括他们的要求而必须在专用条件中编写附加的条文 更为方便; (b)而在原则(a)不适用的情况下,条款中应包含适用于绝大多数合同的规定。

应聘秘书的中英文求职信范文

应聘秘书的中英文求职信范文 Model Chinese and English application letter for Secreta ry

应聘秘书的中英文求职信范文 前言:个人简历是求职者给招聘单位发的一份简要介绍,包括个人的基本信息、过往实习工作经验以及求职目标对应聘工作的简要理解,在编写简历时,要强调工作目标和重点,语言精简,避免可能会使你被淘汰的不相关信息。写出一份出色的个人简历不光是对找工作很有用处,更是让陌生人对本人第一步了解和拉进关系的线。本文档根据个人简历内容要求和特点展开说明,具有实践指导意义,便于学习和使用,本文下载后内容可随意调整修改及打印。 英文版 personal details name: miss. liang xiaoyan nationality: china (mainland) current place: guangzhou height/weight: 163 cm marital status: married age: 27 years career objective

application type: jobseeker preferred job title: admin staff/assistant: assistant 、 shipping: 、 secretary/paper staff: working life: 3 title: no title job type: full time expected start date: in a day expected salary: ¥2,000--¥3,500 preferred working place: guangzhou work experience company's name: guangzhou sanny import and export co., ltdbegin and end date: XX-01-XX-08 enterprise nature: private enterprisesindustry: mechnical follow all the business for old customers. 2> place new order to factory, follow producing process. 3> prepare paper work for custom declaration and inspection.

FIDIC红皮书-施工合同条件__(中英文对照)

Fédération Internationale Des Ingénieurs-Conseils(红皮书--施工合同条件) General Conditions 1.一般规定 General Provisions 1.1 定义 Definitions 在包括专用条件和本通用条件的合同条件(“本合同条件”)中,以下措辞和用语的含义如下所述。除非上下文中另有要求,指当事人和当事各方的词包括公司和其它法律实体。 In the Conditions of Contract ("these Conditions"), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meanings stated. Words indicating persons or parties include corporations and other legal entities, except where the context requires otherwise. 1.1.1 合同 1.1.1 The Contract 1.1.1.1“合同(Contract)”指合同协议书、中标函、投标函、本合同条件、规范、图纸、资料表、以及在合同协议书或中标函中列明的其它进一步的文件(如有时)。 1.1.1.1 "Contract" means the Contract Agreement, the Letter of Acceptance, the Letter of Tender, these Conditions, the Specification, the Drawings, the Schedules, and the further documents (if any) which are listed in the Contract Agreement or in the Letter of Acceptance. 1.1.1.2“合同协议书(Contract Agreement)”指第1.6款【合同协议】中所说明的合同协议(如有时)。 1.1.1.2 "Contract Agreement" means the contract agreement (if any) referred to in Sub-Clause 1.6 [Contract Agreement]. 1.1.1.3“中标函(Letter of Acceptance)”指雇主对投标文件签署的正式接受函,包括其后所附的备忘录(由合同各方达成并签定的协议构成)。在没有此中标函的情况下,“中标函”一词就指合同协议书,颁发或接收中标函的日期就指双方签订合同协议书的日期。 1.1.1.3 "Letter of Acceptance" means the letter of formal acceptance, signed by the Employer, of the Letter of Tender, including any annexed memoranda comprising agreements between and signed by both Parties. If there is no such letter of acceptance, the expression "Letter of Acceptance" means the Contract Agreement and the date of issuing or receiving the Letter of Acceptance means the date of signing the Contract Agreement. 1.1.1.4“投标函(Letter of Tender)”指名称为投标函的文件,由承包商填写,包括已签字的对雇主的工程报价。 1.1.1.4 "Letter of Tender" means the document entitled letter of tender, which was completed by the Contractor and includes the signed offer to the Employer for the Works. 1.1.1.5“规范(Specification)”指合同中名称为规范的文件,及根据合同规定对规范的增加和修改。此文件具体描述了工程。 1.1.1.5 "Specification" means the document entitled specification, as included in the Contract, and any additions and modifications to the specification in accordance with the Contract. Such document specifies the Works. 1.1.1.6“图纸(Drawings)”指合同中规定的工程图纸,及由雇主(或代表)根据合同颁发的对图纸的增加和修改。 1.1.1.6 "Drawings" means the drawings of the Works, as included in the Contract, and any additional and modified drawings issued by (or on behalf of, the Employer in accordance with the Contract. 1.1.1.7“资料表(Schedules)”指合同中名称为资料表的文件,由承包商填写并随投标函提交。此文件可能包括工程量表、数据、列表、及费率和/或单价表。 1.1.1.7 "Schedules" means the document(s) entitled schedules, completed by the Contractor and submitted with the Letter of Tender, as included in the Contract. Such document may include the Bill of Quantities, data, lists, and schedules of rates and/or prices 1.1.1.8“投标文件(Tender)”指投标函和合同中规定的承包商应随投标函提交的其它所有文件。 1.1.1.8 "Tender" means the Letter of Tender and all other documents which the Contractor submitted with the Letter of Tender, as included in the Contract. 1.1.1.9“投标函附录(Appendix to Tender)”指名称为投标函附录并已填写完毕的文件,附于投标函之后并构成投标函的一部分。 1.1.1.9 "Appendix to Tender" means the completed pages entitled appendix to tender which are appended to and form part of the Letter of Tender. 1.1.1.10 “工程量表(Bill of Quantities)”和“计日工计划(Daywork Schedule)”指资料表中如此命名的文件(如有时)。 1.1.1.10 "Bill of Quantities" and "Day work Schedule" mean the documents so named (if any) which are comprised in the

中英文求职信

中英文求职信 提要:随信附上我的简历,如有机会与您面谈,我将十分感谢。即使贵公司认为我还不符合你们的条件,我也将一如既往地关注贵公司的发展,并在此致以最诚挚的祝愿。 更多内容通告 DearSir, Twoyearsasaseniorclerkin*salesdepartmentof*theGreatwallcompanyhave,Ibelievegivenmetheexpe riencetoqualifyforthejobyouadvertisedin51jobwebsite. Since2000Ihavebeenresponsiblefor*allofficedetailsintheadministrationofsales,,Ihavebecomefamili arwiththevarioussalesterritories,andhavealsoinmysparetimeexperienceofhandlingbusinessproblems otherthanmypropersphere. TheyearsbeforeIwasemployedattheGreatwall,Iwasasecretaryfor*LongDragon, Iwasgraduatedat*wuhanUniversity,*twenty-sevenyearsofageandsingle. Iamleavingmypresentpositio mayIseeyouatyourofficetotellyoumoreaboutmyselfandshowyoujusthowwellIcandotheworkyourequ ire. yoursfaithfully, 参考译文: 敬启者: 在51job人才网站上,获悉贵公司招聘人才。本人曾担任长城公司*销售部高级职员两年,自信有充分工作经验,可担任贵公司所招聘的职务。 本人自二零零零年开始,一直担任*售货业务以及函件的撰写工作。在工作期间,除正式业务范围外,与各地区客户颇有来往,并利用公余时间,学会了很多有关商业问题的处理。 在长城公司任职前,我曾在*长龙会计公司担任过秘书工作。在任职期间,学会很多有关会计名词及会计作业程序。 本人*现年二十七岁,未婚,一九九七年毕业于*武汉大学,我希望有机会充分利用自己工作能力,从事更大范围工作之需要,这是我急于离开现职的主要原国。本人现任职的公司老板,对我的工作雄心颇为赞许,因此,愿协助找另谋他职。 如果方便的话,我愿亲赴贵公司办公室晋见阁下,以便详细说明。

FIDIC99版红皮书--施工合同条件

FIDIC施工合同条件(1999年第一版) 用于业主设计的房屋建筑或工程通用条件

引言 国际咨询工程师联合会(FIDIC)现于1999年出版下列四份新的合同标准格式的第一版: ●施工合同条件(Conditions of Contract for Construction) 推荐用于由雇主设计的、或由其代表—工程师设计的房屋建筑或工程(building or engineering works)。在这种合同形式下,承包商一般都按照雇主提供的设计施工。但工程中的某些土木、机械、电力和/或建造工程也可能由承包商设计。 ●永久设备和设计—建造合同条件(Conditions of Contract for Plant and Design-Build) 推荐用于电力和/或机械设备的提供,以及房屋建筑或工程的设计和实施。在这种合同形式下,一般都是由承包商按照雇主的要求设计和提供设备和/或其它工程(可能包括由土木、机械、电力、和/或建造工程的任何组合形式)。 ●EPC/交钥匙项目合同条件(Conditions of Contract for EPC/Turnkey Projects) 适用于在交钥匙的基础上进行的工厂或其它类似设施的加工或能源设备的提供、或基础设施项目和其它类型的开发项目的实施,这种合同条件所适用的

项目(i)对最终价格和施工时间的确定性要求较高,(ii)承包商完全负责项目的设计和施工,雇主基本不参与工作。在交钥匙项目中,一般情况下由承包商实施所有的设计、采购和建造工作:即在“交钥匙”时,提供一个配备完整、可以运行的设施。 合同的简短格式(Short Form of Contract) 推荐用于价值相对较低的建筑或工程。根据工程的类型和具体条件的不同,此格式也适用于价值较高的工程,特别是较简单的、或重复性的、或工期短的工程。在这种合同形式下,一般都是由承包商按照雇主或其代表—工程师提供的设计实施工程,但对于部分或完全由承包商设计的土木、机械、电力、和/或建造工程的合同也同样适用。 建议在国际范围内招标时使用上述格式作为合同基础。在某些国家和地区,特别是当合同条件用于其国内合同时,可能需要对这些格式进行一些改动。FIDIC是按照以英语为官方语言的情况编写的。 在编写本施工合同条件的过程中我们认识到,有许多条款是普遍适用的,但也有一些条款必须根据特定合同的具体情况予以变动。因此,我们将那些对大多数(并非全部)合同都适用的条款编入了通用条件中,以方便使用者将其纳入合同文件。 通用条件和专用条件共同构成了制约合同各方权力和义务的条件。对于每一份具体的合同,都必须编制专用条件,并且必须考虑到通用条件中提到的专用条件中的条款。

求职信中英文对照范文

求职信中英文对照范文 求职信是我们求职过程中的一个重要环节,你知道你的中文求职信怎么翻译成英文吗?下面由为你提供的求职信中英文对照范文,希望能帮到你。 求职信中英文对照范文(一)尊敬的先生/小姐: 您好!我从报纸上看到贵公司的招聘信息,我对网页兼职编辑一职很感兴趣。 我现在是出版社的在职编辑,从1998年获得硕士学位后至今,一直在出版社担任编辑工作。两年以来,对出版社编辑的工作已经有了相当的了解和熟悉。经过出版者工作协会的正规培训和两年的工作经验,我相信我有能力担当贵公司所要求的网页编辑任务。 我对计算机有着非常浓厚的兴趣。我能熟练使用FrontPage和DreamWeaver、PhoteShop等网页制作工具。本人自己做了一个个人主页,日访问量已经达到了100人左右。通过互联网,我不仅学到了很多在日常生活中学不到的东西,而且坐在电脑前轻点鼠标就能尽晓天下事的快乐更是别的任何活动所不及的。 由于编辑业务的性质,决定了我拥有灵活的工作时间安排和方便的办公条件,这一切也在客观上为我的兼职编辑的工作提供了必要的帮助。基于对互联网和编辑事务的精通和喜好,以及我自身的客观

条件和贵公司的要求,我相信贵公司能给我提供施展才能的另一片天空,而且我也相信我的努力能让贵公司的事业更上一层楼。 随信附上我的简历,如有机会与您面谈,我将十分感谢。即使贵公司认为我还不符合你们的条件,我也将一如既往地关注贵公司的发展,并在此致以最诚挚的祝愿。 此致 求职信人:xxx 20xx年xx月xx日 April 13,2000 P.O. Box 36 BIIT University Beijing,China 100000 Dear Sir/Madam: Are you searching for a telecommunications manager with expertise in project management and team leadership? I specialize in creating and implementing high-performance strategies that directly impact growth and profitability of large telecommunications companies. In addition to my knowledge of business processes, I also offer proficiency in telecom software development and cutting-edge technologies. I am relocating to Shenzhen and would be interested in

6 FIDIC红皮书 专用条款2012126

专用条款 1一般规定 1.1定义 可能需要修改某些定义。如: 1.1.3.1 基准日期可定义为某特定的日历日期。 1.1.4.6 融资机构可能要求某种特定的外币。 1.1.4.8 可要求合同当地币为另一种货币。 1.1.6.2 对于跨边境的现场,“国家”(单数)的内容可能不适用。 1.2解释 如果要更为精确地定义“利润”,本款可改为: 范例 在第1.2款的结尾,加上: 在这些合同条件中,包含“费用加上合理利润的”短语的规定,都要求该利润为该费用的二十分之一(5%)。 1.5文件的优先顺序 一般都要对各文件的优先顺序作出规定,以防随后在合同各文件中发现矛盾。如果不准备指定优先顺序,本款可改为: 范例 删去第1.5款,代之以: 组成合同的各文件将被认为是互为说明的。在出现含糊或歧义时,应按照法律决定先后次序。当工程师认为有必要对此类含糊及歧义加以解释时,他有权就此颁发任何指示。 1.6合同协议书 协议书的格式应作为专用条款的附件编入招标文件中:在本指南尾部提供了一个范例。如果需要进行长时间的谈判,最好在合同协议书中记录下接受的合同款额、基准日期和(或)开工日期。适用的法律可能要求必须签订合同协议。 1.14 共同的和各自的责任 对于一个大型的合同来说,可能需要说明对联营体的详细要求。例如,最好要求每个成员提交其在母公司开具的保函:范例格式作为附件A附于本指南结尾。 上述要求在合同生效前适用,并应写入投标文件附录中。雇主希望在早期阶段指定联营体的领导,这样此后合同对方就变得单一,而不希望卷入联营体各方的争端中。雇主应严格审查联营体的协议,且联营体的协议必须经项目融资机构批准。 附加的条款-需保密的细节,如果要求保密,可增加一附加条款: 范例条款 除非按照合同履行义务所需或为了遵守适用的法律之目的,承包商应将合同作为私有和保密的文件。不经雇主的事先同意,承包商不得在任何专业或技术论文中发表、允许发表、或披露工程的任何细节。

大学生兼职求职信(中英文)

大学生兼职求职信(中英文) 献给兼职求职的大学生们: 尊敬的领导: 你好!! 本人是在校学生,对快速成长的贵公司非常感兴趣。从XX日报得知,贵公司提供暑期实习生的职位,在认真阅读了岗位说明之后,我认为本人完全符合贵公司的要求,特此递上这份求职信。 本人在学校学生会各部门中工作和学习,现已升为学生会主席。今年1月份在佛山做过电子产品销售,熟悉各部门业务,包括与客户关系、沟通、及微笑曲线原则。对市场营销、客服服务深有体会和丰厚的实践经验。本人与XX 年曾经到Xx公司参与实习,业绩斐然,获得公司领导的嘉奖,是个难得营销人才。 本人将在暑假放假到XX市兼职学习,如能蒙赐机会,使本人显示如何有助于贵公司达到目标则感激不尽。 我这次暑期实习工作的主要目的是发挥自己的优势为贵公司创造价值,同时继续提升自我能力,并且获得经济上的收益,为明年的上学、生活得到一定保障,望贵公司能给以成全。 我很希望能加盟贵公司,发挥我的潜力。随信附上我的简历。如有机会与您面谈,我将十分感谢。

[大学生兼职求职信] Dear Hiring Manager, I am interested in the part-time position at Sarasota Saddlery advertised in The Sarasotian. I have equine experience, as I have been around horses for over nine years. Not only have I showed and rode horses, but I have also had extensive experience assisting in a barn. Through working with horses, I have acquired a thorough knowle ge of horses, tack, and equine apparel for both horse and rider. While I have equine experience, I also have excellent communication skills and an aptitude for customer service. My past experience as a volunteer at Sarasota Hospital made it necessary for me to focus on providing quality customer service, and also enabled me to work with all types of people. I believe that my communication skills, partnered with my equine knowledge, would make me an asset to your company. Thank you for your consideration. I can be reached at 111-111-1111 or 222-222-2222.. I look forward to hearing from you soon. Sincerely, Your Signature Your Typed Name [大学生兼职求职信] directions: the summer vacation is drawing near. you, liming by name, want to find a part-time job. write an application letter of about 120-150 words within 30 minutes.

FIDIC合同英文版红皮书99版本_secretpart 04_secret

4. The Contractor 4.1 Contractor's General The Contractor shall design (to the extent specified in the Contract), execute and complete the Works in accordance with the Contract and with the Engineer's instructions, and shall remedy any defects in the Works. The Contractor shall provide the Plant and Contractor's Documents specified in the Contract, and all Contractor's Personnel, Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for this design, execution, completion and remedying of defects. The Contractor shall be responsible for the adequacy, stability and safety of all Site operations and of all methods of construction. Except to the extent specified in the Contract, the Contractor (i) shall be responsible for all Contractor's Documents, Temporary Works, and such design of each item of Plant and Materials as is required for the item to be in accordance with the Contract, and (ii) shall not otherwise be responsible for the design or specification of the Permanent Works. The Contractor shall, whenever required by the Engineer, submit details of the arrangements and methods which the Contractor proposes to adopt for the execution of the Works. No significant alteration to these arrangements and methods shall be made without this having previously been notified to the Engineer. If the Contract specifies that the Contractor shall design any part of the Permanent Works, then unless otherwise stated in the Particular Conditions: If the Contract specifies that the Contractor shall design any part of the Permanent Works, then unless otherwise stated in the Particular Conditions: (a) the Contractor shall submit to the Engineer the Contractor's Documents for this part in accordance with the procedures specified in the Contract; (b) these Contractor's Documents shall be in accordance with the Specification and Drawings, shall be written in the language for communications defined in Sub-Clause 1.4 [Law and Language], and shall include additional information required by the Engineer to add to the, Drawings for co-ordination of each Party's designs; (c) the Contractor shall be responsible for this part and it shall, when the Works are completed, be fit for such purposes for which the part is intended as are specified in the Contract; and (d) prior to the commencement of the Tests on Completion, the Contractor shall submit to the Engineer the "as-built" documents and operation and maintenance manuals in accordance with the Specification and in sufficient detail for the Employer to operate, maintain, dismantle, reassemble, adjust and repair this part of the Works. Such part shall not be considered to be completed for the purposes of taking-over under Sub-Clause 10.1 [Taking Over of the Works and

FIDIC红皮书__(中英文对照)

1.1 测量方法 12.2 Method of Measurement 除非合同中另有规定,无论当地惯例如何: Except as otherwise stated in the Contract and notwithstanding local practice: (a) 测量应该是测量每部分永久工程的实际净值,以及 (a) measurement shall be made of the net actual quantity of each item of the Permanent Works, and (b) 测量方法应符合工程量表或其他适用报表。 (b) the method of measurement shall be in accordance with the Bill of Quantities or other applicable Schedules. 1.2 估价 12.3 Evaluation 除非合同中另有规定,工程师应通过对每一项工作的估价,根据第3.5款【决定】,商定或决定合同价格。每项工作的估价是用依据上述第12.1款和第12.2款商定或决定的测量数据乘以此项工作的相应价格费率或价格得到的。 Except as otherwise stated in the Contract, the Engineer shall proceed in accordance with Sub-Clause 3.5 [Determinations] to agree or determine the Contract Price by evaluating each item of work, applying the measurement agreed or determined in accordance with the above Sub-Clauses 12.1 and 12.2 and the appropriate rate or price for the item. 对每一项工作,该项合适的费率或价格应该是合同中对此项工作规定的费率或价格,或者如果没有该项,则为对其类似工作所规定的费率或价格。但是在下列情况下,对这一项工作规定新的费率或价格将是合适的: For each item of work, the appropriate rate or price for the item shall be the rate or price specified for such item in the Contract or, if there is no such item, specified for similar work. However, a new rate or price shall be appropriate for an item of work if: (a) (i) 如果此项工作实际测量的工程量比工程量表或其他报表中规定的工程量的变动大于10%; (i)the measured quantity of the item is changed by ore than 10% from the quantity of this item in the Bill of Quantities or other Schedule, (ii) 工程量的变更与对该项工作规定的具体费率的乘积超过了接受的合同款额的0.01%; (ii) This change in quantity multiplied by such specified rate for this item exceeds 0.01 % of the Accepted Contract Amount, (iii) 由此工程量的变更直接造成该项工作每单位工程量费用的变动超过1%;以及 (iii) this change in quantity directly changes the Cost per unit quantity of this item by more than 1 %, and (iv) 这项工作不是合同中规定的“固定费率项目”; (iv) this item is not specified in the Contract as a "fixed rate item"; or (b) (i) 此工作是根据第13款【变更与调整】的指示进行的; (i) the work is instructed under Clause 13 [V ariations and Adjustments], (ii) 合同中对此项工作未规定费率或价格;且 (ii) no rate or price is specified in the Contract for this item, and (iii) 由于该项工作与合同中的任何工作没有类似的性质或不在类似的条件下进行,故没有一个规定的费率或价格适用。 (iii) no specified rate or price is appropriate because the item of work is not 每种新的费率或价格是对合同中相关费率或价格在考虑到上述(a)、(b)段所描述的适用的事件以后作出的合理调整。如果没有相关的费率或价格,则新的费率或价格应是在考虑任何相关事件以后,从实施工作的合理费用加上合理利润中得到。 Each new rate or price shall be derived from any relevant rates or prices in the Contract, with reasonable adjustments to take account of the matters described in sub-paragraph (a) and/or (b), as applicable. If no rates or prices are relevant for the derivation of a new rate or price, it shall be derived from the reasonable Cost of executing the work, together with reasonable profit, taking account of any other relevant matters. 在商定或决定了一合适的费率或价格之前,工程师还应为期中支付证书决定一临时费率或价格。 Until such time as an appropriate rate or price is agreed or determined, the Engineer shall determine a provisional rate or price for the purposes of Interim Payment Certificates. 1.3 省略 12.4 Omissions 当对任何工作的省略构成部分(或全部)变更且对其价值未达成一致时,如果: Whenever the omission of any work forms part (or all) of a V ariation, the value of which has not been agreed, if:

相关主题