装饰施工合同中英文对照
合同模板
Contract
建筑装饰工程施工合同
Contract
发包方（简称甲方）
Party A:
承包方（简称乙方）：上海装饰设计有限公司
Party B: i-point design (Inspiration Point Design)
根据<中华人民共和国合同法><中华人民共和国消费者权益保护法><中华人民共和国价格法><上海市合同格式条款监督条例>,<上海市建筑市场管理条例>,以及其他有关法律法规规定的原则，结合本工程的具体情况，甲、乙双方在平等、自愿、协商一致的基础上达成如下协议，共同遵守
According to: “PRC Contract Law”, “Law on the Protection of Consumer Interests”, “PRC Price Law”, “Shanghai Su pervision of Contract Terms”, “Shanghai Construction Market Management Regulations”, as well as other laws and regulations relevant to the specific circumstances of this project, parties A and B have hereby equally and voluntarily entered into the following agreement executed on the basis of mutual respect.
一、概况
OVERVIEW
1. 甲方装饰物业系合法物业
Party A is the owner of the property.
2. 乙方为本市经工商行政管理机关核准登记，并可从事装潢装修的企业
Party B is approved and registered with the city industrial and commercial administrative organs as an
enterprise engaged in renovation and decoration.
3. 装饰施工地点
Construction site:
4. 建筑结构：建筑面积平方米，施工面积平方米。
Construction area: total area (including stairwells and other common areas): m2, private living area: m2.
5. 装饰施工内容：住宅装饰,详见附件一<工程估价单>
Structure: residential.
6. 承包方式:详见附件一<工程估价单>
Contractor engagement method: See annex – (quotation).
7. 总价款： .00元，大写(人民币): 元整。
Total price: .00RMB; in words: 元整. Any changes in this price must be agreed
by both parties in writing.
8. 工期:自年月日开工，至年月日前竣工,工时总计天，不含国家法定节假日,乙方委派现场
施工监理为先生，联系方式:
Period: Start:(year)(month)(day); Completion before: (year)(month)(day); Total days
(excluding national holidays):days. Party B's on site construction supervisor will be:
二、关于工程付款及结算的约定
TERMS OF PAYMENT
1. 工程款的付款方式如下
三、关于材料供应的约定
AGREEMENT ON THE SUPPLY OF MATERIALS
1. 乙方提供的材料：乙方供应的材料、设备,如不符合设计、施工要求，应禁止使用。如已使用，对工程造成的损失由
乙方负责。如甲方要另增加材料由甲方供应，并应符合下列规定：
Material provided by Party B: Any materials or equipment supplied by Party B which do not meet the design and construction requirements are prohibited. Any extra materials requested by Party A which were not in the original design must be paid for by Party A.
2. 甲方提供的材料：另拟补充附件<甲方提供材料、设备表>
甲方负责采购供应的材料、设备，应符合设计施工要求的合格产品，并应按时供应到现场。乙方发现甲方提供的材料、设备有质量问题或规格差异，应及时向甲方提出，甲方仍要求使用的，由此造成工程损失，责任由甲方承担。
甲方供应的材料按时抵达现场后，由乙方负责保管
Material provided by Party A: (see the annex: “Table of Materials to be provided by the Owner”). If Party A
acquires materials for the project, it should first check with Party B that the materials match to the design
requirements, and once the materials are in the care of Party B, then Party B is responsible for the materials. If
Party A requires some materials which do not fit to the design then it shall be the responsibility of Party A to pay
any additional costs incurred by Party B.
四、关于工程质量及验收的约定
FULFILMENT OF THIS AGREEMENT
1. 本工程应符合<建筑装饰工程技术规程>和市建设行政主管部门制定的其它地方标准\质量评定验收标准
The execution of this project must be consistent with the “Architectural and Engineering Rules” of the city
administrative departments responsible for the development of buildings and local standards and quality
evaluation acceptance criteria.
2. 本工程由乙方进行设计，提供施工图纸一式两份，双方签字确认
Party B must provide a duplicate copy of the construction designs and drawings, and both copies should be signed by both parties.
3. 甲方提供的材料、设备质量不合格而影响工程质量，其返工费用由甲方承担，工期相应顺延
If materials provided by Party A for the construction do not meet the necessary requirements, Party A shall bear
responsibility for any resulting delays in the completion in the project.
4. 由于乙方原因造成质量事故，其返工费用由乙方承担
If the quality of Party B's work results in any accidents, the liability for such accidents shall be the responsibility of Party B.
5. 在施工过程中，甲方提出设计修改意见及增减工程项目，须提前与乙方联系，在双方签订<工程项目变更单>后，方
能进行该项目的施工、因此影响工程竣工日期的，责任由甲方承担。凡甲方私自与施工人员商定更改施工内容、增加施工项目所引起的一切后果，甲方自负，给乙方造成损失的，甲方应予赔偿
If, during the con struction, Party A wishes to propose a change to the design, he should sign a “Change of
Project” with Party B and must assume responsibility for resulting delays or increase in costs. If Party A secretly
attempts to change to design directly with the construction personnel and this action causes loss to Party B, then Party A must compensate Party B for this loss.
6. 工程验收：乙方负责理隐蔽工程和中间工程的检查与验收手续。由乙方组织专门人员进行验收。一切理隐蔽工程和
中间工程的质量由乙方负责
The standard of work. It is the responsibility of Party B to make sure that all construction works are carried out to the requirements of the design and to make sure that all internal walls and hidden construction parts are to the
required standard.
7. 工程竣工：乙方完工后即应通知甲方验收，甲方应在竣工当日组织验收，并办理验收移交手续，双方签<工程质量
验收单>。如果甲方在规定时间内不能组织验收，须及时通知乙方，另定验收日期。如通过竣工验收，甲方应承认原竣工日期，并承担因此造成的乙方的看管费用和其他相关费用
Project completion. Party B must notify Party A when the project is complete and ready for inspection by Party A.
After inspection both parties must sign an “Engineering Quality Acceptance” document. If Party A is not available to inspect the construction site on the completion date, he must notify Party B of the soonest available date.
Where Party A is not available on the completion date to retake custody of the location, he must pay any extra
costs incurred by Party B.
8. 工程保修期一年。工程竣工验收后甲、乙双方签署<工程保修单>，凭保修单实行保修，保修期一年，从竣工验收签
章之日起算
One year warranty. After completion of the work and signing of the “Single Warranty”, there shall be a one year
warranty on the construction.
五、有关安全生产和防火的约定
SAFE PRODUCTION AND FIRE REGULATIONS
1. 施工图纸和施工说明应符合防火防事故的要求，主要包括电气线路等管道畅通、合格。乙方在施工中应采取必要
的安全防护和消防措施，保障作业人员及相邻关系的安全,防止相邻单位的管道堵塞、渗漏水、停电、物品毁坏等
事故发生
Construction drawings and construction must be in line with fire prevention regulations, and accident prevention requirements. This includes electrical circuits and pipelines. Party B shall take measures to ensure the safety of
workers and neighbors at the constructions site and must prevent leakage of water, interruptions of power and
damage to property.
2. 施工中凡涉及改变房屋结构，拆、改承重墙，加大楼（地）面荷载，由甲方向物业管理部门提出申请，经所在地
建设行政主管部门批准后方能施工
Any changes to the housing structure or demolition or alteration to load bearing walls or increase in floor load
must first be approved by the building property management before construction begins.
3. 双方款项往来均应出具正规收据和发票，以备查验和结算
Both parties must provide money exchange receipts and invoices.
六、其它事项
OTHER MATTERS
1.甲方工作
Party A
1. 甲方应在开工前确认施工图纸并腾出足够的施工空间，以清除影响施工的障碍物。甲方向乙方提供施工需用的
水、电等必备条件，并说明使用注意事项
When Party A confirms the pre-construction and construction drawings, he must also make sure there is
sufficient space available at the construction site for construction to take place. Party A must make sure that
Party B has everything necessary on site for completion of the construction, particularly electricity and water.
2. 做好施工中因临时使用公用部位操作影响邻里关系等的协调工作
Party A must take care of the public relations in the construction site area – particularly with the neighbors.
2. 乙方工作
Party B
1. 参加甲方召集的现场交底
Party B must be available to attend meetings organized by Party A.
2. 乙方按要求组织施工，保质、保量、按期完成施工任务
Party B must follow the construction plans, and the construction must be durable, and must meet the
scheduled completion date.
七、违约责任
LIABILITY FOR BREACH OF CONTRACT
1. 由于甲方原因导致延期开工或中途停工，工期顺延
If Party A causes any delays to the completion of this project, then the scheduled completion date should be
adjusted accordingly.
2. 由于乙方原因逾期竣工的，每逾期一天，乙方向甲方支付工程造价0.1‰(大写:千分之一)的违约金
If Party B causes any delay to the completion of this project, then Party B must pay to Party A a fee of 0.1‰
(in words: 1/1000)of the total overall project fee for each day beyond the scheduled completion date.
3. 甲方未办理有关手续，强行要求乙方拆改原有建筑承重结构及共用设备管线，由此发生的损失或事故（包括罚款）由
甲方负责并承担责任
If Party A instructs Party B to make any alterations to a load bearing wall and Party A has not sought and received permission from the building property management, Party A shall be responsible for any resulting costs and shall indemnify Party B for any additional expenses incurred.
4. 乙方擅自拆改原有建筑承重结构或共用设备管线，由此发生的损失或事故（包括罚款），由乙方负责并承担责任
If Party B makes any unauthorized changes to load bearing walls or building pipelines and such changes result in damages or loss, it shall be the responsibility of Party B to pay for such loss.
5. 工程未办理验收、结算手续，甲方提前使用或擅自动用工程成品由此造成无法验收和损失的,由甲方负责并承担责任
Party A shall be responsible for any extra costs incurred due to his use of the property before the final completion meeting and signing of the “Engineering Quality Acceptance” document.
八、纠纷处理方式
DISPUTES
1. 因工程质量双方发生争议时，凭本合同文本向有关行业协会申请调解，也可向所在区、县建设行政主管部门或消费者
协会投诉
If there is a dispute between the parties, this contract should be submitted to the relevant trade association for
mediation and also to the host district and county building departments in charge of administrative complaints, or to consumer associations.
2. 当事人不愿通过协商、调解解决、或协商、调解不成时，可以按照本合同约定向--上海仲裁委员会申请仲裁--人民法院
提起诉讼
if, after negotiation, mediation and/or consultation, the parties have failed to reach an agreement, then the dispute should be:submitted to the--Shanghai Arbitration Commission--filed as a lawsuit.
九、合同变更和解除
AMENDMENT AND TERMINATION
1.合同经双方签字生效后，双方必须严格遵守。任何一方要求变更合同内容或解除合约，由双方协商解决，经双方签字
确认后生效
After this contract is signed it must be strictly adhered to. After the contract is signed, neither party can leave the contract without agreement of the other party.
2.本合同签订后，工程不得转包
After this contract is signed, the project shall not be sub-contracted.
3.本合同一式两份，甲、乙双方各执 1 份，合同附件为本合同的组成部分，具有同等的法律效力
This contract will be printed and signed in duplicate and each party shall keep a copy.
十、其它约定
FINAL CLAUSES
1.如遇不可抗力因素，工期顺延
In the event of force majeure, this contract will be delayed and resume as soon as practicably possible.
2.其他未在本合同内规定的事项双方协商解决
If any matters arise which are not covered within this contract, they shall be dealt with by mutual consultation
between the two parties.
十一、附件
ANNEX
1. <工程估价单>
Annex 1. Single Warranty
2.办理施工进场手续费清单
Annex 2. Itemized expenditure list of Party B for the construction (e.g. waste removal fees charged by the property management).
3.施工图纸或做法说明
Annex 3. Construction drawings and practice notes.
Party A (Chop): Party B (Chop): 上海巧点装饰设计有限公司Corporation: Company Owner (name):
Company Owner (name): Company Owner (name):
Project Leader: Project Leader:
Address: Address:
Post Code: Post Code:
Phone: Phone:
Fax: Fax:
Bank Name:
Account Name:
Account Number:
Date: 年月日 Date: 年月日
常见的合同通用条款中英文对照
常见的合同通用条款 GENERAL TERMS AND CONDITIONS OF CONTRACT DATED日期 CONTRACT NAME合同名称 by and between合同双方 PARTY A NAME PARTY A甲方名称 and与 PARTY B NAME PARTY B乙方名称 TABLE OF CONTENT PRELIMINARY STATEMENT前言 1. DEFINITIONS定义 2. [OPERATIVE CLAUSES] 具体操作条款 3. CONDITIONS PRECEDENT如有必要，根据交易具体情况设定相应先决条件 4. REPRESENTATIONS AND WARRANTIES 陈述和担保［保证］ 5. TERM合同期限 6. TERMINATION合同终止 7. CONFIDENTIALITY保密义务
8. BREACH OF CONTRACT违约 9. FORCE MAJEURE不可抗力 10. SETTLEMENT OF DISPUTES争议的解决 11. APPLICABLE LAW 适用法律 12. MISCELLANEOUS PROVISIONS其他规定 THIS CONTRACT(“Contract”)is made in [city and province], China on this day of ,200 by and between [Party A name],[Party A entity form] established and existing under the laws of China, with its legal address at [address] (hereinafter referred to as “Party A”), and [Party B name], [Party B entity form] organized and existing under the laws of [Party Bjurisdiction of incoporation] with its legal address at [address] (hereinafter referred to as “Party B”). Party A and Party B shall hereinafter be referred to individually as a “Party ” and collectively as the “Parties”. 本合同于年月日由以下两方在［地点］签订： ［甲方名称］，一家根据中华人民共和国法律组建及存续的［甲方组织形式］，法定地址为［甲方法定地址］（以下简称“甲方”）： ［乙方名称］，一家根据［乙方所在国］法律组建及存续的［乙方组织形式］，法定地址为［乙方法定地址］（以下简称“乙方”）。 甲乙双方以下单独称为“一方”，合称为“双方”。 PRELIMINARY STATEMENT 前言 [add background information if appropriate]［视交易具体情况决定是否应介绍合同背景］ After friendly consultations conducted in accordance with the principles of equality and mutual benefit, the Parties have agreed to [describe subject matter of the Contract] in accordance with Applicable laws and the provisions of this Contract. 双方本着平等互利的原则，经友好协商，依照［相关法律名称］以及其他有关法律，同意按
中英文对照版合同翻译样本
1.Sales Agreement The agreement, (is) made in Beijing this eighth day of August 1993 by ABC Trading Co., Ltd., a Chinese Corporation having its registered office at Beijing, the People’ Repubic of China (hereinafter called “Seller”) and International Tradi ng Co., Ltd., a New York Corporation having its registered office at New York, N.Y., U.S.A. (hereinafter called “Buyer”). 2.WITNESSETH WHEREAS, Seller is engaged in dealing of (product) and desires to sell (product)to Buyer, and WHEREAS, Buyer desires to purchase(product) from Sellers, Now, THEREFORE, it is agreed as follows: 3.Export Contract This Contract is entered into this 5th day of August 1993 between ABC and Trading Co., Ltd. (hereinafter called “Seller”) who agrees to sell, and XYZ Trading Co., Ltd. (hereinafter called “Buyer”) who agrees to buy the following goods on the following terms and condition. 4.Non-Governmental Trading Agreement No. ＿＿This Agreement was made on the＿day of＿19＿, BETWEEN ＿ (hereinafter referred to as the Seller) as the one Side and ＿ (hereinafter referred to as the Buyer) as the one other Side. WHEREAS, the Seller has agreed to sell and the buyer has agreed to buy ＿ (hereinafter referred to as the Goods ) the quantity, specification, and price of which are provided in Schedule A. IT IS HEREBY AGREED AS FOLLOWS: 5.Contract For Joint-Operation Enterprise ＿＿ COMPANY LTD., a company duly organized under the Law of ＿＿ and having its registered office at (hereinafter called “Party A”) AND ＿＿ COMPANY LTD., a company duly organized under the Law of ＿＿ and having its registere d office at (hereinafter called “Party B”) Party A and Party B (hereinafter referred to as the “Parties”) agree to jointly form a Co-operation Venture Company (hereinafter referred to as the “CVC”) in accordance with “the Laws of the People’s Republic of C hina on Joint Ventures Using Chinese and Foreign Investment” and the “Regulations for the Implementation of the Laws of the People’s Republic of China on Joint Ventures Using Chinese and Foreign Investment” and other applicable laws and regulations. 6.MODEL CONTRACT Contract No. Date: Seller: Signed at: Address: Cable Address: Buyer: Address: Cable Address: The Seller and the Buyer have agreed to conclude the following transactions according to the terms and conditions stipulated below: https://www.sodocs.net/doc/ca8553428.html, of Commodity: 2.Specifications: 3.Quantity: 4.Unit Price: 5.Total Price: U.S.$: 6.Packing: 7.Time of Shipment: days after receipt of L/C. 8.Loading Port & Destination Port: From via to . 9.Insurance:
2.劳务合同英文版
EMPLOYMENT CONTRACT Contract No.: Employer (Party A): Employee (Party B): This Employment Contract is made and entered into on the day of______ , ______by and between______ (hereinafter referred to as“Party A”) and ______ (hereinafter referred to a s“ Party B”). 1. Obligations of T wo Parties Party A hereby employs Party B and Party B hereby accepts to be employed by Party A to serve and perform the duties required of him in the job category provided below: (1) ______ (2) ______ (3) ______ … 2. Service Period The term of this Contract shall be for the period of______, commencing upon ______, ______and ending on ______, ______. 3. Working Hours and Working Days Party B’s work days, hours and workweek shall be______ to ______, from ______ to______ , for a total______ hours per week. 4. Salary
国际技术咨询服务合同范本 中英文对照版
编号：_____________ 国际技术咨询服务合同 委托方：___________________________ 咨询方：___________________________ 签订日期：_______年______月______日
中国________________________公司（以下简称委托方）为一方，_____国 __________________________ 公司（以下简称为咨询方）为另一方，双方就 _________________________的技术咨询服务，授权双方代表按下列条款签订本合同。 This Contract is made and entered into through friendly negotiation by and between China_________________________ (hereinafter referred to as “Client”)， as one party， and__________________________ (hereinafter referred to as“Consultant”)，as the other party， concerning the technical consultancy service of________________________， under the following terms and conditions: 第一条合同内容 Article 1 Contents of Technical Consultancy Service 1.1 委托方希望获得咨询方就___________________________提供的技术咨询服务，而咨询方愿意提供此项服务。 Whereas Client desires to obtain the technical consultancy service of from Consultant and Consultant has agreed to perform such services. 1.2 技术咨询服务范围详见本合同附件一。 The Scope of Technical Services is defined in Appendix 1. 1.3 技术咨询服务的进度安排详见本合同附件二。 The Time Schedule for the Services is shown in Appendix 2. 1.4 技术咨询服务的人员安排见本合同附件三。 The Manning Schedule is described in Appendix 3.
国际贸易合同中英文对照版
编号：_______________ 本资料为word版本，可以直接编辑和打 印，感谢您的下载 国际贸易合同中英文对照版 甲方：___________________ 乙方：___________________ 日期：___________________
英文进口合同范本-- 合同编号(Contract No.): 签订日期（Date） : ________________
m 甘售 inr (signed a ° ________ __ The Buyer _________________________________________
Address- C >5H (T E _) -—— ________ f
卖方: The Seller: 地址: Address: 电话(Tel):_ 传真(Fax): 电子邮箱(E-mail):
买卖双方同意按照下列条款签订本合同: The Seller and the Buyer agree to conclude this Contract subject to the terms and conditions stated below: 1. 货物名称、规格和质量( Name, Specifications and Quality of Commodity ): 2. 数量(Quantity ): 允许的溢短装( % more or less allowed ) 3. 单价(Unit Price ): 4. 总值(Total Amount ):
英文销售合同_中英文对照销售合同范本
英文销售合同_中英文对照销售合同范本英文销售合同_中英文对照销售合同范本(一) SALES CONTRACT 合同编号： Contract NO: 签订地点： Signed at: 签订日期： Date: 买方： The Buyers： 卖方： The Sellers： 双方同意按下列条款由买方售出下列商品：
The Buyers agree to buy and the Sellers agree to sell the following goods on terms and conditions as set forth below： (1)商品名称、规格及包装 (1)Name of Commodity ,Specifications and Packing (2)数量 (2)Quantity (3)单价 (3)Unit Price (4)总值 (4)Total Value (装运数量允许有 %的增减) (Shipment Quantity %more or less allowed) (5)装运期限：
(5)Time of Shipment： (6)装运口岸： (6)Port of loading： (7)目的口岸： (7)Port of Destination： (8)保险;由方负责，按本合同总值110%投保_____险。 (8)Insurance：To be covered by the___for 110% of the invoice value against_______. (9)付款：凭保兑的、不可撤销的、可转让的、可分割的即期有电报套汇条款/见票/出票____天期付款信用证，信用证以_____为受益人并允许分批装运和转船。该信用证必须在______前开到卖方，信用证的有效期应为上述装船期后第15天，在中国______到期，否则卖方有权取消本售货合约，不另行通知，并保留因此而发生的一切损失的索赔权。
劳动合同书(中英文对照)
乙方：姓名：性别：出生日： Party B：Name Sex：Date of Birth： 家庭住址：所属地区： Address：Sub District： 通讯地址：电话： Post Address：Contact Phone： 维蒙特工业（广东）有限公司（甲方）聘用乙方为甲方劳动合同制员工。根据《中华人民共和国劳动法》、《广东省劳动合同条例》、《维蒙特工业（广东）有限公司章程》以及中国和广东省已颁布并可公开得到的有关法律法规，甲乙双方本着自愿平等、协商一致的原则，签订本合同。 According to the Labor Law of the P.R. China, as well as the Personnel Regulations of Guangdong Labor Contract, Valmont Industries (Guangdong) Ltd. employs Party B (the employee) as a contract employee. Both parties to this contract sign on the basis of equity, free will, and mutual benefits. 第1条合同期限 Contract Period 1.1本合同有效期自200___年___月___日至200___年___月___日止（含试用期____个月）。 The contract period of employment will be valid from ____/____/_____ (M/D/Y) to ____/____/______ (M/D/Y). During which the period of _______ months will be considered as probationary employment. 1.2在试用期内，甲方发现乙方不符合录用条件的，甲方可以即行解除本合同。 Party A has the right to terminate Party B’s Labor Contract immediately without notification if Party B does not prove to be suitable through the period of probationary employment. 第2条工作岗位、任务 Positions, duties & Responsibilities 2.1 甲方安排乙方在________________部门_____________岗位工作，覆盖岗位为_________________ Party A (the employer) employs Party B (the employee) in the capacity of 2.2 乙方必须按照甲方规定的岗位职责和要求全面完成指标和任务，并接受甲方对其进行的有关考核测评。 Party B is required to fulfill his/her responsibilities completely and accurately as described by Party A and accept performance measurement handled by Party A 2.3 甲方根据生产经营需要及乙方的工作技能和表现，可变更乙方的工作，乙方须服从甲方的调动，如无正当理由，不服从调动 者，甲方可辞退乙方，解除其劳动合同。 Party A has the right to adjust Party B’s position according to the actual business situation and the performance of Party B. Party B must accept Party A’s arrangement. 第3条工作条件、劳动保护 Labor Conditions & Labor Protection 3.1 甲方实行每周40小时工作制。对特殊岗位可实行不定时工作制。 Party B’s normal working time will not exceed 40 hours per week, whereas it’s flexible for some special position holders. 3.2 甲方因生产经营原因需要乙方加班时，乙方应服从。同时甲方应按规定支付乙方加班费报酬作补偿。 If it is necessary for Party A to request Party B to put in overtime, Party B must be subordinated to request of Party A. Party A shall provide Party B with economic compensation according to relevant regulations. 3.3 甲方为乙方提供必要的工作条件，根据国家劳动法则提供符合中国政府规定的劳动安全卫生条件和提供必要的劳动保护用品， 保证乙方在人身安全及个体不受危害的环境条件下工作，对女职工及未成年工按《劳动法》的规定酌情予以特殊劳动保护。 Party A must provide Party B with a safe and non-toxic working environment, necessary safety measures to guarantee safe working conditions of Party B, according to National Safety and Sanitation Standards. Party A shall provide special protection measures for female and underage employees according to the Labor Law. 3.4 甲方认为乙方的健康状况将会对工作或其他员工造成不利影响时，甲方有权按制度采取相应的措施，并有权要求乙方进行健 康检查，乙方不应拒绝。 If Party A thinks Party B’s healthiness will effect to the work or other staffs, Party A will have the authority to correspond and will have the authority to ask Party B to have a physical check-up, at same time the Party B should not to refuse. 3.5 乙方在被聘用期间，甲方负责对乙方进行岗位职责、技能、安全规程、职业道德及相关规章制度的教育和培训，乙方须积极 配合，并根据岗位职责要求努力提高自身的技能。 Party A is in charge of various training such as technical training, Position principles, safety operations, Company’s regulations and provision, etc. within the employment period. Party B shall accept the training with positive attitude for raising his/her work efficiency. 第4条劳动报酬 Payroll
会员服务协议中英文对照.doc
会员服务协议中英文对照 ［作者：中国法律英语网转贴自：中国法律英语网点击数：448 更新时间： 2006-01-10 文章录入：admin ］ 会员服务协议 AGREEMENT 根据中华人民共和国合同法及相关法律法规规定，北京$$$有限公司（以下简称“本公司”）及会员根据本协议所列条文，以及同意此协议受法律所约束的情况下，一致达成如下协议﹕ Beijing $$$ Co., Ltd. (“the Company”) and the Member, intending to be legally bound, and in consideration of the mutual promises and covenants contained herein, agree as follows: 1. 服务 Service 本协议所指的服务，是指本公司将自己所有或第三方合法所有并授权的法律资料置于互联网上，会员通过账号及密码登录本公司网站数据库，按照《会员章程》及《订阅表格》所列的权限查询各类资料。 The “Service” herein referred to, is the search and retrieval service through which the member can read on the Internet the Company’s own legal information or legal information legally obtained from third parties. The right to access to the Service is through a set of login name and password provided by the Company to the Member. 2. 适用 Application 2.1
外贸合同中英文对照
S ALES CONTRA C T NOo : BS0812 5 DATE： NOV. 6 , 2008 THE S ELLER： BLUE SKY INTE R NATI0 NAL TRADING CO o ,LTD ? 118# 5TH NORTH RI NG ROAD, BE I GINQ P.R. CHINA THE BUYER： STAR CORPORATION 5 KINGROA D DU BAI, UAE T h i s C o ntra c t is made by and b e tw e e n the Buyer and S e llei; wh e reby the Buy e r agree to bu y and the Seller a gree to sell the un d ermen tioned c ommodity a c c ording to t lie term s a nd co n ditions st i pulat e d b e 1 o w 数量和金额可以上下浮动5% P A C K I NG： 2 0 piece s of Baby B 1 anke t s a r e p acked i n one
expo r t sta n dar d c a rt o n, solid co 1 or and s ize i n the s a me c a r ton. 包装：2 0条童毯被装进-项输出品标准硬纸盒、一样颜色利尺寸的装在相同的硬纸盒。 MAR KS： Shipping m a rk i n c 1 udes S TAR ,S/C No。,sty 1 e No o , port o f des tina t ion and c a r t on N o .陵头：运输吱头包括S TA R （公司名）、合同（sal e s contract）号码，款式号码，目的港和纸箱号码 Side mark m u st s how the co 1 o r t the s i ze of c a rton and p i ece s p e r carto n ? 侧唆头必须显示纸箱颜色，规格和每箱（童毯）条数 T I ME OF SHIPMENT：装运期 Wi t liin 60daysupon receip t o f the L / C wh i c h acc ord with relevant c buses o ft h i s Contract。收到符合合同的信用证^六十天内 POR T OF LOADI NG AND DESTINAT I ON：FromTianj i n, Chi nato Dub a i, UAE 装运港目的港 T r an s shipment i s all owed an d p artial shipme nt i s pro h i b i te d o 转运被允许，而且分批装运被禁止. IN S URANCE： To beeffecte d b y the Sei 1 e r for 1 1 0% o f inv o i c e value c ov e r in g Al 1 Ris k s and War Risk s a s p er CIC o f PICC d ated 01/01/1981.保险：卖方按合同金额的110%投保包含的一切险和战争险依照1981年的P I CC规则的CIC条约。 TERMS OF PAYMENT： By irrev o c able Let t er of Cre d i t at 60 d ay s a f t er s igh t, reaching the S e 1 1 er not 1 a te r t han Nov.30, 200 8 an d rem a in i ng v a li d f or n e gotiation in Ch i n a fo r f ur t her 15 days after th e a ffected s hipment o I n c a se of late ar r i v al of the L/C, the Se 1 1 er s hall not be liable for any d e lay i n ship me n t and shall ha v e the right t o res c i n d the c o ntra c t and / o r c 1 aim for damages0付款期限：不可撤销信用证，见票后6 0天付款.卖方收到信用证不得晚于08年月30号.偿付通知议付在中国装船后15天内提交单据，如果信用证迟到,卖方将不负责装船中的任何延迟而且将有权利废止合同和I或损害要求（赔偿）。 DOCUMENTS：文件 +Si g n e d invoice i n t r ipli cate, one or i g i nal o f w hicli s lioul d b e c ertifiedby Chamber of Com mere e o r CCPIT an d legalize d b y UAE em b ass y/co n su 1 ate in sei 1 er's country ? +签署的单据一式三份，一份正本应该被商会或CC PIT （贸促会）检定而且在卖方的国家被阿拉伯联合大公国大使馆I领事法律上认为正当。 +Ful 1 set （3/3） of c 1 ean on board o cean b i 11 o f lading ma r k e d <4fr e ight pr e paid" made out t o orde r blank en d o r sed n o t i fying th e app 1 icant. +全套（3 I 3）清洁海运提单标记"船货预付”空白抬头提单通知申请人。 +In s u r a n ce polic y i n dup lica te end o r s ed in b 1 a nk. +保险单一式两份空白背书。 +P a c k ing list i n t r i p 1 i c ate o +包装目录一式三份 + Cer t if i c at e of ori g in c erti f i e d by Cham b er of C o mmerce o r C CP I T and 1 e ga 1 i zed by U AE em b as s y/consulate in s e lie r "s countr y ?
中英文对照工程施工合同2范本
工程施工合同 Contract 合同编号( Contract NO. )： 签订日期( Date )： 发包方（简称甲方） Party A: 承包方（简称乙方）： Party B: 根据《中华人民共和国合同法》以及其他有关法律法规规定的原则，结合本工程的具体情况，甲、乙双方在平等、自愿、协商一致的基础上达成如下协议，共同遵守。 According to “P.R.C Contract Law”,and other relevant laws and regulations to the specific circumstances of this project, parties A and B have hereby equally and voluntarily entered into the following agreement executed on the basis of mutual respect. 1.工程概况 Project overview 1.1工程名称： Project name: 1.2工程地点： Project location: 1.3工程范围： A. 新研发中心和新厂房的网络综合布线系统的施工； B. 数据中心的建设，主要包含：数据中心的装饰工程、电气系统、空调系统、机房闭路监控系统、机房门禁系统、消防系统改造、机柜系统等。 Project contents: A. The new R & D and new plant construction of network cabling systems; B. Data Center, mainly includes: data center decoration and electrical systems, air-conditioning systems, CCTV systems, access control systems, firefighting system reform, server rack systems. 1.4开工条件：合同生效后，甲方预付款到位和现场具备开工条件。 Start conditions: After the commencement of the contract, Party A has started advance and on-site conditions in place.
劳务协议书-Labor-Service-Agreement-中英文对照 派遣员工劳务合同(中英文)最新合同版本
劳务协议书 Labor Service Agreement 甲方（单位名称）： Party A (Company Name): 乙方（劳务者姓名）： Party B (Service provider Name): 性别：男身份证/护照号码：联系电话： Gender: Male ID/Passport No.: Tel No.： 家庭住址： Home Address: 根据《中华人民共和国民法通则》、《中华人民共和国合同法》和有关规定，甲乙双方经平等协商一致，自愿签订本劳务协议，共同遵守本协议所列条款。 According to the "General Principles of Civil Law of the People's Republic of China", "Contract Law of the Peop le's Republic of China” and relevant regulations, after equal negotiation, Both parties agree to sign and comply with this labor service agreement 第一条乙方承担的劳务内容为：。甲乙双方可另行约定岗位具体职责及要求，详见职责说明书，附件一。 Article 1 Party B’s Job duty is：Both parties agree on Job duties and requirement as in, Annex I, Job Description. 第二条乙方的工作地点为：,根据甲方工作需要，经甲乙双方协调一致，可变更工作地点。Article 2 Working location of Party B is: , which can be changed on the basis of mutual agreement as per Par ty A’s business requirements. 第三条本协议期限为自年年月日生效，至年年月日终止。其中试用期从/ 年/ 月/ 日起至/ 年/ 月/ 日止。 Article 3, The Agreement period is from to . The probation is / month(s), from / to / . 第四条在协议期间，甲方的责任和义务是：
中英文对照合同11
采购合同 (Purchasing Contract) 合同编号(Contract NO.)： 合同签订地点(Signed At)：东营 签订时间(Date)：年月日出卖人(Seller)： 买受人(Buyer)： 鉴于：根据【中华人民共和国合同法】及相关法律法规，本着平等自愿、等价有偿、诚实诚信的原则，经双方协商一致，订立本合同。 According to the Contract law of the People's Republic of China and relevant laws and regulations,we conclude the contract on the basis of equality, voluntariness,compensation of equal value and sincerity. 第一条标的、数量、价款及交（提）货时间 Item 1 (object)Quantity Price and Delivery time 物资编码名称及规格型号Commodity code and type 生产厂家 Manufacture r 计量单位 Unit 数量 Quantity 单价（元） Unit Price 总金额（元） Total Amount 备注 Note 不含税总金额（人民币） Total Amount (V AT excluded) 交提货时间、数量：年月日至年月日全部交货。 Delivery time: From to 第二条质量标准：标准代号、编号和标准名称：GB150-98. Item 2 Quality standard: standard code,serial number and standard name:GB150-98. 第三条出卖人对质量负责的条件及期限 Item 3 Conditions and time limits that Sellers shall be held responsibility for 1. 质量负责条件和期限按正常运行12个月止执行。 1. Quality responsible conditions and time limits shall not be valid until the product has been functioning properly for 12 months 2. 出卖人对标的物的质量负责，产品均附质检报告单，质量保证书。如果出卖人知道或 者应当知道所处卖产品存在质量缺陷，所承担的质量保证期限不受前款质量负责期限的约束，应依法承担相应责任。 2. Sellers shall be responsible for the quality of the marks.The products should include the Quality Inspection Report and Quality Guarantee.If the sellers know or should know the products they sell with defects in quality,the quality assurance time limits should not be subject to the previous quality responsibility deadline and they should be held due responsibility for it. 第四条包装标准：标准包装，产品所需包装由出卖人合理包装，适合水运和长途内陆运输，防潮，防湿，防锈，防震。 Item 4 Packaging standard: Standard packaging, the sellers should package the products properly, it should be suitable for shipment and long distance inland transportation. The packaging of the products should be resistant of dampness, moisture, rust and shock. 第五条随机的必备品、配件、技术资料、工具数量及供应方法：随设备交货一起交齐。 Item 5 The accompanied necessary materia l, accessories, technical information ,quantity of